HomeMy WebLinkAbout122396 CC Agenda in compliance with the Americans with Disabilities Act, if you need special assistance to participate in
this meeting, please contact the office of the City Clerk (909) 694-6444. Notification 48 hours prior to
a meeting will enable the City to make reasonable arrangements to ensure accessibility to that meeting
[28 CFR 35.102.35.104 ADA Title III
AGENDA
TEMECULA CITY COUNCIL
AN ADJOURNED REGULAR MEETING
CITY COUNCIL CHAMBERS
43200 BUSINESS PARK DRIVE
DECEMBER 23, 1996 - 8:30 AM
CALL TO ORDER: Mayor Karel Lindemans presiding
Flag Salute: Councilmember Stone
ROLL CALL: Birdsall, Ford, Roberts, Stone, Lindemans
PUBLIC COMMENTS
A total of 30 minutes is provided so members of the public can address the Council on
items that appear within the Consent Calendar or ones that are not listed on the agenda.
Speakers are limited to two (2) minutes each. If you desire to speak to the Council on an
item which is listed on the Consent Calendar or a matter not listed on the Agenda, a pink
"Request to Speak" form should be filled out and filed with the City Clerk.
When you are called to speak, please come forward and state your name for the record.
For all Public Hearing or Council Business matters on the agenda, a "Request to Speak"
form must be filed with the City Clerk before the Council gets to that item. There is a five
(5) minute time limit for individual speakers.
CITY COUNCIL REPORTS
Reports by the members of the City Council on matters not on the agenda will be made at
this time. A total, not to exceed, ten (1 0) minutes will be devoted to these reports.
CONSENT CALENDAR
1Standard Ordinance Adoption Procedure
RECOMMENDATION:
1.1Motion to waive the reading of the text of all ordinances and resolutions included in
the agenda.
R:\Agenda\l 22396
2Second Readinci of Ordinance No. 96-24
RECOMMENDATION:
2.1Adopt an ordinance entitled:
ORDINANCE NO. 96-24
AN ORDINANCE OF THE CITY COUNCIL OF THE CITY OF TEMECULA, CALIFORNIA,
APPROVING A DEVELOPMENT AGREEMENT BETWEEN THE CITY OF TEMECULA,
FOREST CITY DEVELOPMENT INC., AND LGA-7, INC., FOR APPROXIMATELY 179
ACRES LOCATED AT THE SOUTHEAST CORNER OF WINCHESTER ROAD AND YNEZ
ROAD (PLANNING APPLICATION NO. PA96-0333)
CITY MANAGER'S REPORT
CITY ATTORNEY'S REPORT
ADJOURNMENT
Next regular meeting: January 14, 1996, 7:00 PM City Council Chambers, 43200 Business Park
Drive, Temecula, California.
R:\Agenda\l 22396 2
ITEM NO. 1
ITEM NO. 2
ORDINANCE NO. 96-24
AN ORDINANCE OF THE CITY COUNCIIL OF THE CITY OF
TEM[ECULA, CALIFORNIA APPROVING A DEVELOPMENT
AGREEMIENT BETWEEN THE CITY OF TEMIECULA, FOREST
CITY DEVELOPMENT CALIFORNIA INC., AND LGA-7, INC.,
FOR APPROXD4ATELY 179 ACRES LOCATED AT THE
SOUTHEAST CORNER OF WINCHESTER ROAD AND YNEZ
ROAD (PLANNING APPLICATION NO. PA96-0333)
THE CITY COUNCH, OF THE CITY OF TEMIECULA DOES ORDAIN
AS FOLLOWS:
Section 1. The City Council hereby finds determines, and declares as follows:
a. Section 65864 cl =. of the Government Code of the State of California
and Temecula City Resolution No. 91-52 authorize the execution of development
agreements establishing and maintaining requirements applicable to the development of
real property;
b. In accordance with the procedure specified in said statutes and
Resolution, Forest City Development California, Inc. ("Developer") and LGA-7, Inc.
("Owner") have jointly filed with the City of Temecula an application for a
Development Agreement ("Development Agreement") for approximately 179 acres
located at the southeast comer of Winchester Road and Ynez Road ("Property") for a
regional mall and retail commercial uses consistent with Specific Plan No. 263, which
application has been reviewed and accepted for filing by the Community Development
Director;
C. Notice of the City's intention to consider adoption of the Development
Agreement and to consider the findings under the California Environmental Quality Act
that a Supplemental EIR or Subsequent EIR is not required has been duly given in the
form and manner required by law for both the public hearing before the Planning
Commission and the public hearing before the City Council;
(1) Notice of the public hearings before the Planning Commission
and City Council was published in a newspaper of general circulation at least
ten (10) days before the public hearings, and mailed or delivered at least ten
(10) days prior to the hearings to the project applicants and to each agency
expected to provide water, sewer, schools, police protection, and fire
protection, and to all property owners within six hundred feet (600') of the
Property as shown on the latest equalized assessment roll;
I
(2) Notice of the public hearings before the Planning Commission
and City Council included the date, time, and place of the public hearing, the
identity of the hearing body, a general explanation of the matter to be
considered, a general description in text or diagram of the location of the real
property that is the subject of the hearing, and notice of the need to exhaust
administrative remedies;
d. The Planning Commission conducted a duly noticed public hearing on
the Development Agreement on December 16, 1996 at which time the Planning
Commission heard and considered all of the written material and oral comments
presented to it on the proposed environmental findings and the proposed Development
Agreement;
e. The City Council conducted a duly noticed public hearing on the
Development Agreement on December 17, 1996 at which time the City Council heard
and considered all of the written material and oral comments presented to it on the
proposed environmental findings and the proposed Development Agreement;
Section 2. The City Council of the City of Temecula further finds,
determines and declares that:
a. The Development Agreement is consistent with the objectives, policies,
general land uses, and programs specified in the City of Temecula's General Plan in
that:
(1) The Development Agreement makes reasonable provision for the
use of the Property for commercial development consistent with the General
Plan's land use designation of Community Commercial, Professional Office and
Public/Institutional Facilities for the Property which provide for commercial
development;
(2) The Development Agreement and development on the Property
will provide for the creation of jobs within the City, enhance the balance of
housing and jobs within the City as provided in the Growth Management/Public
Facility, Land Use, and Economic Development Elements of the General Plan;
b. The Development Agreement is consistent with Specific Plan 263 in
which the Property is located in that:
(1) The Development Agreement provides for commercial
development pursuant to and in conformance with the terms of Specific Plan
263;
Ords\96-24 2
(2) The specific land uses proposed for the Project as set forth in the
Development Agreement are specifically allowed by Specific Plan No. 263;
(3) The Development Agreement provides for the actual construction
of the regional public improvements by the City as described in Specific Plan
263;
(4) The Applicable Rules set forth in the Development Agreement do
not change the provisions of the Specific Plan, but clarifies the uses to be
allowed and standards to be imposed where the Specific Plan provides for
alternatives;
C. The Development Agreement is in conformity with the public
convenience, general welfare, and good land use practice because it makes reasonable
provision for a balance of land uses compatible with the remainder of the City;
d. The Development Agreement will not be detrimental to, and in fact
enhances, the health, safety, or general welfare because it provides adequate assurances
for the protection thereof through the implementation of the Applicable Rules;
e. The City Council's approval of the Development Agreement by this
Ordinance is based upon evidence and findings of the Planning Commission and the
evidence presented at the hearings before the Planning Commission and the City
Council on the Development Agreement;
f. The following benefits, among others, will accrue to the people of the
City of Temecula from the Development Agreement:
(1)Generation of municipal revenue;
(2)Construction of needed public infrastructure facilities;
(3) Acceleration of both the timely development of subject property
as well as the payment of municipal revenue;
(4) Enhancement of quality of life for surrounding residents with the
timely development through the elimination of dust and nuisance of partially
improved lots and providing retail development necessary to serve the
community; and
(5)Payment of Public Facility Fees.
Ords%96-24 3
9. By separate resolufion adopted prior to this Ordinance, the City Council
has determined that environmental impacts for the commercial development described
in the Development Agreement were contemplated and fully and properly analyzed in
Environmental Impact Report No. 340, approved July 13, 1993, and the Addendum
thereto approved October 11, 1994 and that none of the findings described in Public
Resources Code Section 21166, 14 Cal. Admin. Code Sections 15162 or 15163
requiring a subsequent environmental impact report for the Development Agreement
exist.
Section 3. The Development Agreement is hereby approved in substantially the
form attached and incorporated herein by this reference as Exhibit A. The Mayor is hereby
authorized and directed to evidence such approval by executing this Agreement for, and in the
name of, the City of Temecula and the City Clerk is directed to attest thereto.
Section 4. The City Clerk shall certify to the adoption of this Ordinance and
shall cause the same to be posted as required by law.
PASSED, APPROVED AND ADOPTED this 14th day of December, 1996.
Karel F. Lindemans, Mayor
ATTEST:
June S. Greek, CMC
City Clerk
[SEAL]
Ords\96-24 4
STATE OF CALIFORNIA )
COUNTY OF RIVERSIDE ss
CITY OF TEMECULA
1, June S. Greek, City Clerk of the City of Temecula, do hereby certify that the
foregoing Ordinance No. 96-24 was duly introduced and placed upon its first reading at a
regular meeting of the City Council on the 17th day of December, 1996, and that thereafter,
said Ordinance was duly adopted and passed at a regular meeting of the City Council on the
23rd day of December 1996, the following vote, to wit:
AYES: COUNCILMEMBERS:
NOES: COUNCILMEMBERS:
ABSENT:COUNCILMEMBERS:
June S. Greek, CMC
City Clerk
Ords\96-24 5
EXEMPT FROM RECORDER'S FEES
Pursuant to Government
Code 6103, 27383
Recording Requested By
and When Recorded Return to:
CITY CLERK CITY OF TEMECULA
43200 Business Park Drive
Temecula, CA 92590-3606
DEVELOPMENT AGREEMENT
BY AND BETWEEN
THE CITY OF TEMECULA,
FOREST CITY DEVELOPMENT CALIFORNIA, INC.,
A CALIFORNIA CORPORATION, AND
LGA-7, INC., AN ILLINOIS CORPORATION
Development Agreement
No. DV96-
THIS AGREEMENT SHALL BE RECORDED WITHIN TEN DAYS
OF EXECUTION BY ALL PARTIES HERETO PURSUANT TO
THE REQUIREMENTS OF GOVERNMENT CODE 65868.5
Final: December 13, 1996 11086-00006 pt 1480121.4
TABLE OF CONTENTS
AGREEMENT
1. Recitals 1
2. Definitions 3
3. Interests of Owner and Developer 4
4. Binding Effect 4
5. Negation of Agency 4
6.Development Standards for the Property;
Applicable Rules 5
7. Regional Public Improvements 8
8.Acknowledgments, Agreements and Assurances on
the Part of the Developer 13
9.Acknowledgments, Agreements and Assurances on
the Part of the City 14
10. Cooperation and Implementation 17
11. Compliance; Termination; Modifications And Amendments. 20
12. Operating Memoranda 21
13. Term of Agreement 22
14. Tax Reimbursements 22
15. Administration of Agreement and Resolution of Disputes 22
16. Transfers and Assignments 24
17. Mortgage Protection 25
18. Notices 26
19. Severability and Termination 28
20. Time of Essence 28
21. Force Majeure 28
22. Waiver 28
23. No Third Party Beneficiaries 28
24. Attorneys' Fees 28
25. Incorporation of Exhibits 29
26. Authority to Execute; Binding Effect 29
27. Entire Agreement; Conflicts 29
i
Final: December 13, 1996 11086-00006 pt 1480121.4
EXHIBITS
EXHIBIT A LEGAL DESCRIPTION
Exhibit A-1 Property
Exhibit A-2Developer's Parcels--Mall Parcel
Exhibit A-3Developer's Parcels--Power Center Parcel
Exhibit A-4Owner's Parcel
EXHIBIT BCITY OF TEMECULA FURNISHED
INFRASTRUCTURE
Exhibit B-1Street Improvements
Exhibit B-2Traffic Signals
Exhibit B-3Underground Power Lines
Exhibit B-4Storm Drain Improvements
Final: December 13, 1996 11086-00006 pt 1480121.4
DEVELOPMENT AGREEMENT
This Development Agreement ("Agreement") is made this 17th day of
December, 1996, by and between the CITY OF TEMECULA, a general law city in the State
of California (the "City"), FOREST CITY DEVELOPMENT CALIFORNIA, INC., a
California corporation (the "Developer"), and LGA-7, INC., an Illinois Corporation (the
flOwner"). In consideration of the mutual covenants and agreements contained in this
Agreement, the parties hereto agree as follows:
I . Recitals. This Agreement is made with respect to the following facts
and for the following purposes, each of which is acknowledged as true and correct by the
parties:
a. The City is authorized pursuant to Government Code Sections 65864
through 65869.5 (the "Development Agreement Statutes") to enter into binding
agreements with persons or entities having legal or equitable interests in real property
for the development of such property in order to establish certainty in the
development process.
b. The property which is the subject of this Development Agreement (the
"Property") consists of approximately 179 acres. Developer is contractually entitled
to acquire from the Owner approximately 120 acres of the Property, which shall be
known as the "Developer's Parcels." The remaining approximately 59 acres will
remain owned by the Owner and shall be known as the " Owner's Parcel." The
Property is legally described on Exhibit A-1, the Developer's Parcels is legally
described on Exhibits A-2 ("Mall Parcel") and A-3 ("Power Center Parcel"), and the
Owner's Parcel is legally described on Exhibit A-4. All such exhibits are attached to
this Agreement. In the event the Developer does not purchase the Developer's
Parcels from Owner and Developer's rights to purchase the Developer's Parcels
expires or are terminated, Section 3 of this Agreement provides that the Owner may
elect to terminate this Agreement or to assume all rights and obligations of the
Developer.
C. The parties desire to enter into this Agreement in conformance with the
Development Agreement Statutes and Resolution 91-52 of the City of Temecula in
order to achieve the development of the "Temecula Regional Center" on Developer's
Parcels and in order to achieve the retail development of an as yet unidentified project
on the Own'er's Parcel. As of the date of this Agreement, no specific project is
planned for the Owner's Parcel. The parties likewise desire to provide land uses on
the Property consistent with Specific Plan 263 and provide public services and urban
infrastructure, all in the promotion of the health, safety, and general welfare of the
residents of the City of Temecula.
Final: December 13, 1996 11086-00006 pt 1480121.4
d. The development of the Developer's Parcels includes a regional
shopping mall, anchored by department stores and containing retail shops and other
commercial uses on the Mall Parcel (the "Regional Center"), and a separate power
center on the Power Center Parcel ("Power Center"), all in accordance with the
provisions of this Agreement and with Specific Plan 263. (The Regional Center and
the Power Center shall together constitute the "Developer's Project.") Owner's
Parcel shall be allowed to develop in accordance with the Applicable Rules described
in Section 6 of this Agreement. The Developer's Project and the terms of this
Agreement are consistent with the land uses and amenities described in Specific Plan
263. The Developer's Project will be the largest commercial development within the
City of Temecula and requires the assurances set forth in this Development
Agreement with respect to the identification of specific development standards and
requirements in order to accommodate the development of the Developer's Parcels
and the development on the Owner's Parcel.
e. On December 16, 1996, the Planning Commission of the City of
Temecula held a duly noticed public hearing on the Developer's and Owner's
application for the Development Agreement (Planning Application No. PA96-00333)
and by Resolution No. f'@ -,41 recommended to the City Council approval of this
Agreement.
f. On December 17, 1996, the City Council of the City of Temecula held
a duly noticed public hearing on the Developer's and Owner's application for the
Development Agreement (Planning Application No. PA96-00333) and on
- i 2-1 I'l @ 1996 the City Council adopted Ordinance
No. @ - @ approving this Agreement.
9- An environmental review has been conducted and approved for this
Agreement in accordance with the California Environmental Quality Act.
h. The City desires to obtain the binding agreement of the Developer and
Owner for the development of the Property in accordance with the provisions of this
Agreement.
i. The Developer desires to obtain the binding agreement of the City to
permit the Developer to develop the Developer's Project on the Developer's Parcels
in accordance with the "Applicable Rules" (as hereinafter defined) and this
Agreement.
i. The Owner desires to obtain the binding agreement of the City to
permit the Owner to develop the Owner's Parcel in accordance with the "Applicable
Rules" (as hereinafter defined) and this Agreement.
Final: December 13, 1996 1108 pt 1480121.4 -2-
k. Developer and Owner have applied to the City in accordance with
applicable procedures for approval of this mutually binding Agreement. The Planning
Commission and City Council of the City have given notice of intention to consider
the Agreement, have conducted public hearings thereon pursuant to the Government
Code, and have found that the provisions of this Agreement are consistent with the
Specific Plan 263 and the City's General Plan.
1. This Agreement is consistent with the public health, safety, and welfare
needs of the residents of the City and the surrounding region. The City has
specifically considered and approved the impact and benefits of the development of
the Property in accordance with this Agreement upon the welfare of the region.
M. This Agreement will bind the City to the terms and obligations
specified in this Agreement and will limit, to the degree specified in the Agreement
and under State law, the future exercise of the City's ability to delay, postpone,
preclude or regulate development on the Property, except as provided for herein.
n. In accordance with the Development Agreement Statutes, this
Agreement eliirninates uncertainty in the planning process and provides for the orderly
development of the Property. Further, this Agreement eliminates uncertainty about
the validity of exactions imposed by the City, allows installation of necessary
improvements, provides for public services necessary for the region with incidental
benefits for the Property, and generally serves the public interest within the City of
Temecula and the surrounding region.
2.Definitions. In this Agreement, unless the context otherwise requires:
a. "Applicable Rules" means the development standards and restrictions
set forth in Section 6 of this Agreement which shall govern the use and development
of the Property and shall amend and supersede any conflicting or inconsistent
provisions of zoning ordinances, regulations or other City requirements relating to
development of property within the City.
b. "Discretionary Actions; Discretionary Approvals" are actions which
require the exercise of judgement or a discretionary decision, and which contemplate
and authorize the imposition of revisions or additional conditions, by the City,
including any board, commission, or department of the City and any officer or
employee of the City; as opposed to actions which in the process of approving or
disapproving a permit or other entitlement merely requires the City, including any
board, commission, or department of the City and any officer or employee of the
City, to determine whether there has been compliance with applicable statutes,
ordinances, regulations, or conditions of approval.
Final: December 13, 1996 1108 pt 1480121.4 -3-
C. "Effective Date" is the date the ordinance approving this Agreement
becomes effective.
d. "Future Approvals" means any action in implementation of
development of the Property which requires Discretionary Approvals pursuant to the
Applicable Rules, including, without limitation, parcel maps, tentative subdivision
maps, development plans, and conditional use permits. Upon approval of any of the
Future Approvals, as they may be amended from time to time, they shall become part
of the Applicable Rules, and Developer or Owner, as the case may be, shall have a
"vested right," as that term is defined under California law, in and to such Future
Approvals by virtue of this Agreement.
3.Interests of Owner and Developer.
a. The Owner represents to the City that, as of the Effective Date,
it is the owner of the entire Property, subject to encumbrances, easements, covenants,
conditions, restrictions, and other matters of record. Owner and Developer represent
to the City that as of the Effective Date of this Agreement, Developer is contractually
entitled to acquire the Developer's Parcels.
b. In the event the Developer does not purchase either or both
Developer's Parcels from Owner and Developer's rights to purchase either or both the
Developer's Parcels expires or terminates, Owner may, as to the property not
purchased by Developer, elect, in its discretion, to terminate this Agreement or to
assume all rights of the Developer pursuant to this Agreement for the benefit of the
Owner and to assume all obligations of the Developer under this Agreement. Such an
election shall be effective upon written notice from the Owner to the City and
Developer, in which event Developer shall no longer be a party to this Agreement nor
have any rights, duties or obligations hereunder as to the property not purchased.
The notice shall contain a representation of the Owner to the City, that Developer has
not purchased the applicable Developer's Parcels, Developer is no longer entitled to
purchase the applicable Developer's Parcels, and that Owner elects to either terminate
the Agreement as to such parcels or to assume and be bound by all of the benefits and
obligations of Developer as to such parcels as set forth in the Agreement. If Owner
elects to assume and be bound by all of the benefits and obligations of Developer,
then at such time all references in this Agreement to Developer with respect to such
parcels shall mean and include only Owner.
4. Bindiniz Effect. This Agreement, and all of the terms and conditions of
this Agreement, shall run with the land comprising the Property and shall be binding upon
and inure to the benefit of the parties and their respective assigns, heirs, or other successors
in interest.
Final: December 13, 1996 11086 pt 1480121.4 -4-
5. Negation of Agency. The parties acknowledge that, in entering into
and performing under this Agreement, each is acting as an independent entity and not as an
agent of the other in any respect. Nothing contained herein or in any document executed in
connection herewith shall be construed as making the City, Developer, and Owner joint
venturers, partners, agents of the other, or employer/employee. Developer is not the agent
of the Owner. Except as otherwise set forth in Section 3.b. above, neither Owner nor
Developer shall be entitled to bind the other nor to modify this Agreement without the
express written consent of the other and nothing contained herein or in any document
executed in connection herewith shall be construed as allowing Developer or Owner to bind
the other or to modify this Agreement without the express written consent of the other.
Developer and Owner each acknowledge that this consent requirement may cause delays in
modifying or amending this Agreement and implementing the development proposed thereby.
6. Development Standards for the Property: Applicable Rules. The
following development standards and restrictions set forth in this Section shall govern the use
and development of the Developer's Project, Developer's Parcels, and the Owner's Parcel
and shall constitute the Applicable Rules, except as otherwise provided herein, and shall
amend and supersede any conflicting or inconsistent provisions of existing zoning ordinances,
regulations or other City requirements relating to development of the Property and any
subsequent changes to the Applicable Rules as specifically described in Section 9.b.:
a. The following ordinances and regulations shall be part of the
Applicable Rules:
(1)The City's General Plan as it exists on the Effective Date;
(2)Specific Plan No. 263, as it exists on the Effective Date;
(3) The Mitigation Plan of Environmental Impact Report No. 340,
as it exists on the Effective Date;
(4) The City's Development Code, which is set forth in Title 17 of
the Temecula Municipal Code, as it exists on the Effective Date;
(5) Those portions of Riverside County Ordinance No. 348,
Zoning, adopted by the City by City Ordinance No. 90-04, which have not
been superseded by the City's Development Code;
(6) Those portions of Riverside County Ordinance No. 460,
Subdivisions, adopted by the City by City Ordinance No. 90-04, which have
not been superseded by the City's Development Code or other City
Ordinances;
Final: December 13, 1996 11086-00006 pt 1480121.4 -5-
(7) The building and construction codes as adopted by the City of
Temecula pursuant to State law (including but not limited to, Uniform Building
Code, Uniform Mechanical Code, and similar construction codes) which are
(A) applicable generally to structures within the City, (B) in effect on the date
of issuance of building pen-nits for structures on the Property, and (C) as may
be in effect on the date of issuance of building permits for subsequent
modifications of those structures;
(8) Such other ordinances, rules, regulations, and official policies
governing permitted uses of the Property, density, design, improvement,
development fees, and construction standards and specifications applicable to
the development of the Property in force at the time of the Effective Date,
which are not in conflict with the development standards set forth in this
Section;
(9) The land uses permitted on the Developer's Parcels and the
Owner's Parcel include all of the allowable land uses permitted in Specific
Plan No. 263 or those permitted by the Planning Director (Director of
Community Development) pursuant to Paragraph a. at page 111-56, Vol. I of
Specific Plan No. 263. The parties acknowledge and are aware of that the
Planning Commission in approving a development on the Property will apply
the standards set forth in Specific Plan 263 and are also aware of the language
set forth in Paragraph c. 1) at page 111-42, Vol. 1 of Specific Plan 263 which
provides:
"It is important to note that not all uses allowed in Planning Area 1 are
necessarily expected to occur. For this reason, some of the above
design features may not be appropriate nor economically feasible. For
this reason, only the concept of a 'Main Street' is discussed in depth
above. Additional options for possible development in Planning Area 1
are discussed in Section IV, Design Guidelines, in this Specific Plan. "
b. The following development standards and procedures shall also govern
the development of the Property and shall be part of the Applicable Rules:
(1) The number of parking spaces required by the Development
Code may be reduced by the Planning Commission upon a finding that a lesser
number of parking spaces would be adequate for the Property based on the
results of a parking study utilizing generally accepted methodologies for shared
parking studies and conducted by a qualified consultant;
(2) The Director of Community Development may approve
alternatives to the lighting requirements of the Development Code, if requested
by the Developer, so long as the Director finds that the alternatives will
Fi@: December 13, 19% 1108@00006 pt 1480121.4 -6-
mitigate the light pollution to the same extent as the Development Code
requirements and the proposed lighting program is consistent with Palomar
Lighting District requirements;
(3) Developer and Owner shall pay a maximum Development
Mitigation Fee in the amount of two dollars ($2.00) per square foot of gross
leasable building area in lieu of all other City development fees for structures
on the Property or any other City fees or charges related to development,
except as otherwise provided herein in accordance with the following
provisions;
i. The Development Mitigation Fee shall be applicable to
all areas of the Property, including retail space, except for the
department store anchors for the Mall on the Developer's Parcels, to
which no City development fees shall apply;
ii. The Development Mitigation Fee shall be in effect for
the duration of this Agreement;
iii. The Development Mitigation Fee shall be paid at the
time of issuance of a building permit for the structure; and
iv. Developer and Owner shall pay the Development
Mitigation Fee only for their respective parcels and neither Developer
nor Owner shall be responsible for the payment of the fee for the other
party's parcel(s).
(4) Developer and Owner shall pay all building plan check and
building inspection fees for work on their respective parcels on the Property in
effect at the time an application for a grading permit or building permit is
applied for;
(5) The public works plan check fee and public works inspection fee
for public improvements constructed and installed by the Developer shall be
the actual costs to the City to conduct the plan check and inspections plus ten
percent (10%) of those actual costs for administrative overhead;
(6) The Developer shall be entitled to install a major site identity
sign identifying the Project in accordance with the following regulations;
i. The sign shall be located on property with a perpetual
easement in favor of Developer and shall be located within 50 feet of
the right of way for the I-15 Freeway and within an area of 2500 feet
Final: Decembcr 13, 1996 11086-00006 pt 1480121.4 -7-
north or south of the right of way for Winchester Road or such other
location permitted by the City and accepted by the Developer;
ii. Upon the acquisition of the sign property by Developer,
Developer shall notify the City Manager and the City Manager is
hereby authorized to and shall enter in to an amendment to this
Development Agreement adding the sign property to the legal
description of the Developer's Parcels and causing the sign property to
be subject to the terms of this Agreement;
iii. The sign shall not exceed ninety four (94) feet in height.
The minimum area of the sign shall be five hundred (500) square feet
of sign area, subject to future approval of additional sign area by the
Director of Community Development;
iv. The design of the sign shall be of high architectural
quality, compatible with th e area surrounding it, and shall be consistent
with the sign program for the Property adopted by the Planning
Commission;
V. The sign shall be an identification sign for the
Developer's Project which shall contain only the names of the anchor
tenants and project name and shall not contain changeable messages;
vi. The location, size and design of the sign shall be subject
to Development Plan approval and all applicable governmental permit
requirements and City shall be the lead agency in obtaining all required
permits and approvals for the sign, including, without limitation,
environmental review, permits from CalTrans and all other
governmental agencies, and a building permit for construction of the
sign;
(7) Developer and Owner, as to their respective Parcels, shall
construct and install all public improvements set forth in Specific Plan 263 and
in the Conditions of Approval of Specific Plan 263 as applicable to the
development it actually undertakes except for those Regional Public
Improvements being constructed and installed by the City pursuant to Section 7
of this Agreement; and
(8) Subsequent development plans submitted for individual users
that are substantially in conformance with the Specific Plan 263 may be
approved by the Director of Community Development.
Final: December 13, 1996 11086-00006 pt 1480121.4 -8-
C. Prior to the Effective Date, City and Developer shall use reasonable
efforts to identify, assemble and copy three identical sets of the Applicable Rules, for
the City, Developer, and Owner so that if it becomes necessary in the future to refer
to any of the Applicable Rules, there will be a common set of the Applicable Rules
available to all parties.
7. Regional Public Improvements. In accordance with the schedule of
completion described in Section 7.c., City agrees to and shall, at its own cost and expense,
except as otherwise provided herein, design, construct, install and finally complete, in a
diligent, timely and workmanlike manner, and in conformance with the Applicable Rules, the
following regional public infrastructure improvements ("Regional Public Improvements"):
a. Obligation to Construct. The City shall construct, install, finally
complete and thereafter maintain all perimeter road improvements for the Property in
accordance with all requirements of Specific Plan 263, the Applicable Rules and as
shown in Exhibit B-1, and as described in further detail as follows:
(1) Construct, install and finally complete all Winchester Road
improvements, including, but not limited to, adding and upgrading street
lighting, transit facilities and turn outs if required, all required signalization or
signal upgrades, landscaping, permanent irrigation systems between street curb
and sidewalks, Class II bike lanes, signs, striping, turning lanes, driveway
approaches, and sidewalks on the south side of the roadway from Ynez Road
to Margarita Road.
(2) Construct, install and finally complete all Ynez Road
improvements, including, but not limited to, adding and upgrading street
lighting, landscaping, permanent irrigation systems in medians if required,
transit facilities and turn outs if required, all required signalization or signal
upgrades, signs, turning lanes, Class II bike lanes, driveway approaches, and
sidewalks on the east side of the roadway from Overland Drive to Winchester
Road.
(3) Construct, install, and finally complete full width Margarita
Road from Winchester Road to Solana Way improvements in a manner
consistent with and pursuant to existing Margarita Road improvement plans
including, but not limited to, landscaped medians and irrigation systems,
slopes, driveway approaches, transit facilities and turn outs if required, all
required signalization or signal upgrades, stonn drainage facilities, Class II
bike lanes, and sidewalk and street lights on the west side of the roadway from
Winchester Road to Overland Drive. Notwithstanding anything to the contrary
in Specific Plan 263, neither Developer nor Owner shall be required to issue,
provide or post any bond, collateral or other security for the work of
Finai: December 13, 1996 11086-00006 pt 1480121.4 -9-
improvement contemplated by this Section 7. a. (3) nor for any of the other
Regional Public Improvements.
(4) Construct, install, and finally complete full width Overland
Drive road improvements, including, but not limited to, driveway approaches,
transit facilities and turn outs if required, all required signalization or signal
upgrades, storm drainage facilities, Class II bike lanes, and a sidewalk and
street light on the north side of the roadway from Margarita Road to Ynez
Road.
(5) Cause the completion of the overcrossing of the I-15 Freeway
from Ynez to Jefferson at Overland Road ("Overland Overpass") in accordance
with existing Community Facilities District 88-12 ("CFD 88-12") plans and
subject to the funding of the land acquisition and construction costs of the
Overland Overpass by CFD 88-12; the parties acknowledge and agree that
City shall have no obligation to fund the Overland Overpass through its
General Fund, development impact fees it may have collected for traffic
improvements or other funds it may control;
(6) Construct, install and finally complete new, or upgrade or
remodel existing, traffic signals and all necessary or associated street
improvements as may be required at the intersections of Solana Way and
Margarita Road, all traffic signals to be used in conjunction with the Overland
Drive freeway overpass, as well as the traffic signals at the other locations
illustrated in Exhibit B-2.
(7) Underground the overhead power and communications lines on
the south side of Winchester Road from Ynez to Margarita Roads as illustrated
in Exhibit B-3.
(8) Construct, install and finally complete regional storm drainage
systems and courses through the Property as illustrated in Exhibit B-4 and
which are further described as:
A. Two (2) main underground storm drains equivalent to a
forty eight (48) inch pipe or greater, running through the Property and
discharging at the box culvert in Ynez Road.
B.A detention basin on the east side of Margarita Road.
C. An underground storm drain on the east side of
Margarita Road.
Final: December 13, 1996 1108 pt 1480121.4 -10-
D. Box culverts and associated approaches and outlet
structures for the open channel crossing at Margarita Road and
Overland Drive including any remedial grading to the interim open
channel between the two streets.
b. Permits and Approvals; Release of Owner and Develo]2er. Prior to
commencement of construction of any portion or segment of the Regional Public
Improvements, the City shall, at its own costs and expense, obtain all grading
permits, building permits, construction permits, development permits and other
licenses, permits, approvals, or consents which are required, either by or from the
City or any department thereof, or by or from CalTrans, Riverside County or the San
Diego County Regional Water Quality Control Board, or by or from the State of
California Department of Fish and Game, the State of California Water Resources
Control Board, the U. S. Army Corps of Engineers, the U. S. Fish and Wildlife
Service, the National Pollutant Discharge Elimination System or any other
goverrunental or quasi-govermuental agency asserting jurisdiction over the Property.
If, and to the extent, that the City's obligation pursuant to this Agreement to construct
the Regional Public Improvements conflicts with the obligation of the "Developer" or
"Applicant" pursuant to Specific Plan 263 to construct the same items, the provisions
of this Agreement shall prevail.
C. C@'s Time to CoMplete. The City shall finally complete all of the
Regional Public Improvements, at its own cost and expense, pursuant to the following
schedule:
(1) The City shall award design contracts for the Regional Public
Improvements (excluding the Overland Overpass) promptly following the
Effective Date.
(2) On condition that the Developer delivers written notice to the
City at least thirty (30) days prior to commencement of any major grading by
Developer on any portion of Developer's Parcels, the City shall, prior to
actual commencement of major grading by Developer: (A) Take all actions,
adopt all resolutions, make all findings and adopt all ordinances as are
necessary or required to approve the final plans and specifications for the
construction and installation of all Regional Public Improvements (excluding
the Overland Overpass); and (B) complete advertising all required Notices
Inviting Bids for the construction of the Regional Public Improvements
(excluding the Overland Overpass). Developer shall diligently pursue major
grading once it has commenced.
(3) The City shall construct and finally complete installation of all
Regional Public Improvements (except the Overland Overpass) prior to the
date the Developer opens the Regional Center for business, provided,
Final: December 13, 1996 1108 pt 1480121.4 -11-
however, the City shall not be required to commence construction of said
Regional Public Improvements until such time as the Developer commences
construction of the Regional Center. Developer shall notify City of the
completion of all contingencies to its financing of the construction of the
Regional Center on the Developer's Parcels, that financing is ready to close,
and the date construction of the Regional Center is expected to commence
within five (5) working days of the completion of the final contingency for
financing of the Regional Center.
(4) City shall use its reasonable best efforts to cause the
.commencement of construction of the Overland Overpass within thirty six (36)
months following opening of the Regional Center, subject to the funding of the
Overland Overpass through CFD 88-12 and the conditions of approval for
Specific Plan 263. Provided, however, all traffic signals which are intended to
operate in conjunction with the Overland Overpass shall be constructed and
installed by the City pursuant to Section 7.a.(4) above, at the time required by
Section 7.c.(3) above.
d. Cooperation. City and the Developer recognize that the design and
construction of all Regional Public Improvements (including the Overland Overpass),
the Regional Center, and (when finally approved) the project on the Owner's Parcel,
will require close coordination between all of the parties. Each of the parties agrees
to coordinate the design and construction of their respective projects and
improvements with each other, to the extent reasonably practicable, in order to
facilitate the orderly development of the Property and to avoid conflicts in design and
construction. In this regard: (i) the City, Developer, and Owner shall use their
respective best efforts to create working procedures and whereby each shall give
notice to the other in a timely manner of their respective activities that impact on the
other, and (ii) Developer and Owner shall have the opportunity to review and
comment upon the design and construction contracts for all Regional Public
Improvements, but shall do so in an expeditious manner so as not to impede the
City's design and construction schedule for the Regional Public Improvements.
Developer and Owner acknowledge that City will bid the Regional Public
Improvements in accordance with the bidding requirements of the Public Contract
Code and will require payment of prevailing wages for the construction of the
Regional Public Improvements pursuant to Labor Code Sections 1770, et seq.
e. City's Failure to Colnplete Regional Public IMprovements. The City's
failure to timely complete construction and installation of the Regional Public
Improvements in accordance with the terms of this Agreement shall constitute a
material breach of this Agreement. In said event, Developer and Owner shall have all
of the rights and remedies granted to them in this Agreement. In addition, in such an
event, Developer and Owner shall have the right to require the City, at no cost or
expense to the Developer or Owner, to amend the Applicable Rules (including, but
Final: December 13, 1996 11086-00006 pt 1480121.4 -12-
not limited to, this Agreement and Specific Plan 263), in accordance with law, to
provide that Developer and Owner may proceed with the development, construction,
and installation of their respective projects on the Property, without any requirement
that the unfinished Regional Public Improvements be completed.
f. Coordination and Relocation of Utiliiy Systems, Dedication of Land.
The City agrees to coordinate installation of all utility delivery systems required by
the Regional Public Improvements with the installation of planned utility delivery
systems in the Property, as well as coordinate the required relocation of any existing
utility delivery systems and that construction delays may occur as a consequence
thereof. Developer, Owner, and the City agree in good faith to mutually determine
which portions of the Property are required for construction and installation of the
Regional Public Improvements (except for the Overland Overpass which is to be
constructed on land not owned by the Developer or Owner). In this regard, all
parties agree to use their best efforts to have the planned utility delivery systems to be
installed within the dedicated roads. When mutually determined as aforesaid,
Developer and Owner, as appropriate, shall dedicate the land required for the
Regional Public Improvements to the City, and City agrees to accept and thereafter
operate and maintain said land at no cost to the Developer or Owner. Provided,
however, if the portion(s) of the Property to be dedicated are encumbered with liens
securing repayment of any Mello-Roos Community Facilities District bonds or any
City of Temecula, County of Riverside, or State of California real property taxes,
special taxes or assessments, then Developer and Owner, as appropriate, shall (1) use
their best efforts to cause the liens to be reallocated to the remaining portions of the
Property or the remaining portions of the applicable community facilities district or
assessment district or (2) in the event the liens cannot be so reallocated, be obligated
to pay the taxes or assessments on the portion of the Property dedicated to the City.
Developer and Owner shall not be required to pay the entire assessment lien and shall
not be required to secure a lien-free release from the Agency or entity holding the
referenced liens. City shall be entitled to take the dedicated property either free and
clear of all encumbrances, assessments or liens, or, in the event the Developer or
Owner, as appropriate, cannot so deliver the dedicated land, the City shall take the
land subject only to the lien or assessment of the governmental entity and Developer
or Owner, or their successors and assigns, as appropriate, shall continue to pay the
taxes or assessment on the dedicated land.
9. Ajzreement Re Owner's Parcel. In recognition of certain regional
benefits associated with the storm drain planned to carry storm runoff across the
Owner's property from Margarita Road to the southwesterly side of Overland Drive,
City and Owner agree that at the time a master plan is submitted by Owner for the
full Owner's Parcel, the City agrees to negotiate in good faith with the Owner in an
attempt to fund the costs of said storm drain based on the potential tax benefits to be
realized by the City from the proposed project on the Owner's Parcel.
Final: December 13, 1996 1108 6 pt 1480121.4 -13-
8. Acknowledgments, Ajzreements and Assurances on the Part of the
Developer.
a. Developer's Faithful Performance. The parties acknowledge and agree
that Developer's faithful performance in developing the Developer's Project on the
Developer's Parcels and in constructing and installing certain public improvements
and complying with the Applicable Rules and Owner's development of a project on
the Owner's Parcel in accordance with the Applicable Rules will fulfill substantial
public needs. The City acknowledges and agrees that there is good and valuable
consideration to the City resulting from Developer's and Owner's assurances and
faithful performance thereof and that same is in balance with the benefits conferred by
the City on the Developer's Project. The parties further acknowledge and agree that
the exchanged consideration hereunder is fair, just and reasonable. Developer and
Owner each acknowledge that the consideration is reasonably related to the type and
extent of the impacts of their respective projects on the community and the Property,
and further acknowledge that the consideration is necessary to mitigate the direct and
indirect impacts caused by the development on the Property. The parties further
acknowledge that development of the Owner's Parcel alone without the development
of the Regional Center on the Developer's Parcels will not provide the benefits to the
City described above and would not in and of themselves justify the commitments of
the City pursuant to this Agreement.
b. Developer's Agreement to Develop. In consideration of the foregoing
and the City's assurance set out in Section 9 below, Developer hereby agrees to use
its reasonable best efforts, in accordance with its own reasonable business judgement,
taking into consideration market conditions, financing and other economic factors, to
develop the Mall Parcel and, if acquired, the Power Center Parcel in accordance with
the terms and conditions of this Agreement and the Applicable Rules.
Notwithstanding anything in this Agreement to the contrary, Owner shall have the
right, but shall not be obligated to construct a project on the Owner's Parcel during
the term of this Agreement.
C. Oblijzations to be Non-Recourse. As a material element of this
Agreement, and as an inducement to Owner and Developer to enter into this
Agreement, each of the parties understands and agrees that the City's remedies for
breach of the obligations of Developer and Owner under this Agreement shall be
limited as described in Section 15, below.
9. Acknowledgements, Agreements and Assurances on the Part of the
City. In order to effectuate the provisions of this Agreement, and in consideration for the
Developer and Owner to obligate themselves to carry out the covenants and conditions set
forth in the preceding Section 8 of this Agreement, the City hereby agrees and assures
Developer that Developer will be permitted to carry out and complete the development of the
Developer's Project on the Developer's Parcels, and agrees and assures Owner that Owner
Final: December 13, 1996 1108 pt 1480121.4 -14-
will be permitted to develop a project on the Owner's Parcel, each in accordance with the
Applicable Rules, subject to the terms and conditions of this Agreement and the Applicable
Rules. Therefore, the City hereby agrees and acknowledges that:
a. Entitlement to Develop. The Developer is hereby granted the vested
right to develop the Developer's Project on the Developer's Parcels to the extent and
in the manner provided in this Agreement, subject to the Applicable Rules and the
Future Approvals. Owner is hereby granted the vested right to develop a project on
the Owner's Parcel in accordance with the Applicable Rules and the Future
Approvals, provided, however, that said rights of Owner shall not vest until such time
as the Developer has commenced construction of the Regional Center on the
Developer's Parcels.
b. Conflictiniz Enactments. Any change in the Applicable Rules,
including, without limitation, any change in any applicable general area or specific
plan, zoning, subdivision or building regulation, adopted or becoming effective after
the Effective Date, including, without limitation, any such change by means of a
Future Approval, an ordinance, initiative, resolution, policy, order or moratorium,
initiated or instituted for any reason whatsoever and adopted by the Council, the
Planning Commission or any other board, commission or department of City, or any
officer or employee thereof, or by the electorate, as the case may be, which would,
absent this Agreement, otherwise be applicable to the Property and which would
conflict in any way with or be more restrictive than the Applicable Rules
("Subsequent Rules"), shall not be applied by City to any part of the Property.
Developer or Owner may give City written notice of its election to have any
Subsequent Rule applied to such portion of the Property as it may own, in which case
such Subsequent Rule shall be deemed to be an Applicable Rule insofar as that
portion of the Property is concerned.
C. Permitted Conditions. Provided Developer's or Owner's applications
for any Future Approvals are consistent with this Agreement and the Applicable
Rules, City shall grant the Future Approvals in accordance with the Applicable Rules
and authorize development of the Property for the uses and to the density and
regulations as described herein. City shall have the right to impose reasonable
conditions in connection with Future Approvals and, in approving tentative
subdivision maps, impose dedications for rights of way or easements for public
access, utilities, water, sewers, and drainage necessary for the Project or other
developments on the Property; provided, however, such conditions and dedications
shall not be inconsistent with the Applicable Rules in effect prior to imposition of the
new requirement nor inconsistent with the development of the Project as contemplated
by this Agreement; and, provided further, such conditions and dedication shall not
impose additional infrastructure or public improvement obligations in excess of those
identified in this Agreement. The party applying for a Future Approval may protest
any conditions, dedications or fees while continuing to develop the Property; such a
Final: December 13, 1996 1108 6 pt 1480121.4 -15-
protest by the party applying shall not delay or stop the issuance of building permits
or certificates of occupancy.
d. Tenn of Maps and Other Project Approvals. Pursuant to California
Government Code Sections 66452.6(l) and 65863.9, the term of any subdivision or
parcel map that may be processed on all or any portion of the Property and the term
of each of the Project Approvals, including the tentative map and any Future
Approvals shall be extended for a period of time through the scheduled termination
date of this Agreement as set forth in Section 13 below.
e. Timing of Development. Because the California Supreme Court held in
Pardee Construction Co. v. Ciiy of Camarillo, 37 Cal.3d 465 (1984) that failure of
the parties to provide for the timing of development resulted in a later adopted
initiative restricting the timing of development to prevail over the parties' agreement,
it is the intent of the Developer, Owner, and the City to cure that deficiency by
acknowledging and providing that Developer or Owner shall have the right (without
the obligation) to develop the their respective portions of the Property in such order
and at such rate and at such time as each deems appropriate within the exercise of its
subjective business judgement, subject to the terms of this Agreement.
f. Moratorium. No City-imposed moratorium or other limitation (whether
relating to the rate, timing or sequencing of the development or construction of all or
any part of the Property, whether imposed by ordinance, initiative, resolution, policy,
order or otherwise, and whether enacted by the Council, an agency of City, the
electorate, or otherwise) affecting parcel or subdivision maps (whether tentative,
vesting tentative or final), building permits, occupancy certificates or other
entitlements to use or service (including, without limitation, water and sewer, should
the City ever provide such services) approved, issued or granted within City, or
portions of City, shall apply to the Property to the extent such moratorium or other
limitation is in conflict with this Agreement; provided, however, the provisions of this
Section shall not affect City's compliance with moratoria or other limitation mandated
by other governmental agencies or court-imposed moratoria or other limitation.
9- Pen-nitted Fees and Exactions. Except as otherwise provided in this
Agreement, City shall only charge and impose those fees and exactions, including,
without limitation, dedications and any other fees or taxes (including excise,
construction or any other taxes) relating to development or the privilege of developing
the Property, as are set forth in the Applicable Rules described in Section 6 of this
Agreement. This Section shall not be applicable to the following fees and taxes and
shall not be construed to limit the authority of City to:
(1) Charge application, processing, and permit fees for land use
approvals, building permits, and other similar permits and entitlements, which
fees are designed to reimburse City's expenses attributable to processing such
Final: December 13, 1996 11086-00006 pt 1480121.4 -16-
application, provided, however, said application, processing and permitting
fees shall not exceed the fees that are charged by the City generally to
applicants, on a nondiscriminatory basis for similar approvals, permits, or
entitlements granted by City;
(2) Impose or levy general or special taxes, including but not
limited to, property taxes, sales taxes, parcel taxes, transient occupancy taxes,
business taxes, which may be applied to the Property or to businesses
occupying the Property, provided, however, that the tax is of general
applicability citywide and does not burden the Property disproportionately to
other retail development within the City; or
(3) Collect such fees or exactions as are imposed and set by
governmental entities not controlled by City but which are required to be
collected by City.
10. Cooperation and Implementation. The City agrees that it will cooperate
with Developer and Owner to the fullest extent reasonable and feasible to implement this
Agreement. Upon satisfactory performance by Developer of all required preliminary
conditions, actions and payments, the City will commence and in a timely manner proceed to
complete all steps necessary for the implementation of this Agreement and the development
of the Developer's Project on the Developer's Parcels or a project on the Owner's Parcel in
accordance with the terms of this Agreement; provided, however, City acknowledges and
agrees that nothing herein shall obligate Owner to construct a project on Owner's Parcel.
Developer and Owner shall, in a timely manner, provide the City with all documents, plans,
and other information necessary for the City to carry out its obligations. Additionally:
a. Further Assurances: Covenant to Sign Documents. Each party shall
take all actions and do all things, and execute, with acknowledgment or affidavit, if
required, any and all documents and writings, that may be necessary or proper to
achieve the purposes and objectives of this Agreement.
b. Reimbursement and Apportiom-nent. Although the parties do not
contemplate a condition of a Future Approval requiring excess capacity or size of
required dedications or public facilities beyond that required by the Applicable Rules,
nothing in this Agreement precludes City, Developer or Owner from entering into any
reimbursement agreements for the portion (if any) of the cost of any dedications,
public facilities and/or infrastructure that City, pursuant to this Agreement, may
require as conditions of the Future Approvals, to the extent that they are in excess of
those reasonably necessary to mitigate the impacts of the Project or development on
the Property.
C. Processing. Upon satisfactory completion by Developer of all required
preliminary actions and payments of appropriate processing fees, if any, City shall,
Final: December 13, 1996 11086-00006 pt 1480121.4 -17-
subject to all legal requirements, promptly initiate, diligently process, and complete at
the earliest possible time all required steps, and expeditiously act upon any approvals
and permits necessary for the development by Developer or Owner of the Property in
accordance with this Agreement, including, but not limited to, the following:
(1) the processing of applications for and issuing of all discretionary
approvals requiring the exercise of judgement and deliberation by City,
including without limitation, the Future Approvals;
(2)the holding of any required public hearings;
(3) the processing of applications for and issuing of all ministerial
approvals requiring the determination of conformance with the Applicable
Rules, including, without limitation, site plans, grading plans, improvement
plans, building plans and specifications, and ministerial issuance of one or
more final maps, zoning clearances, grading permits, improvement permits,
wall permits, building permits, lot line adjustments, encroachment permits,
temporary use permits, certificates of use and occupancy and approvals and
entitlements and related matters as necessary for the completion of the
development of the Property ("Ministerial Approvals").
d. Processiniz During Third Pariy Liti . The filing of any third party
lawsuit(s) against City, Developer, or Owner relating to this Agreement or to other
development issues affecting the Property shall not delay or stop the development,
processing or construction of the Property, approval of the Future Approvals, or
issuance of Ministerial Approvals, unless the third party obtains a court order
preventing the activity. City shall not stipulate or fail to oppose the issuance of any
such order.
e. State, Federal or Case Law. Where any state, federal or case law
allows City to exercise any discretion or take any act with respect to that law, City
shall, in an expeditious and timely manner, at the earliest possible time, (i) exercise
its discretion in such a way as to be consistent with, and carry out the terms of, this
Agreement and (ii) take such other actions as may be necessary to carry out in good
faith the terms of this Agreement.
f.Defense of Agreement. City agrees to and shall timely take all actions
which are necessary or required to uphold the validity and enforceability of this
Agreement and the Applicable Rules, subject to the indemnification provisions of this
Section. If this Agreement is adjudicated or determined to be invalid or
unenforceable, the City agrees, subject to all legal requirements, to consider and
implement all modifications to this Agreement which are necessary or required to
render it valid and enforceable to the extent permitted by applicable law; provided,
however, City shall not be required to construct or install any additional public
Final: December 13, 1996 1108 pt 1480121.4 -18-
improvements beyond those described in this Agreement as of the Effective Date nor
expend funds for items not described in this Agreement as of the Effective Date.
Developer and Owner jointly and severally agree to indemnify, protect, defend, and
hold harmless the City and its agencies, instrumentalities and their respective officers,
employees and agents (collectively, "Indemnified Parties") from any and all claims,
actions, or proceedings ("Claims") brought against any of the Indemnified Parties by
any third party or entity not a signatory to this Agreement, which Claims seek to
attack, set aside, void, or annul or seek monetary damages as a result of, the City's
approval of this Agreement or any amendment thereto and which Claiirns are not
caused by the gross negligence or wilful misconduct of any of the Indemnified
Parties. Each Indemnified Party agrees to and shall promptly notify the Developer
and Owner in writing of any Claims within ten (10) calendar days from their receipt
of any Claim. Each Indemnified Party shall cooperate fully with Owner and
Developer in the defense of all Claims. No Indemnified Party shall settle a claim
without the consent of the Developer, which consent shall not be unreasonably
withheld. Developer and Owner shall be entitled to select legal counsel of their
choice (which counsel is/are reasonably acceptable to City) to conduct such defense
and which legal counsel shall represent the City (and Developer and Owner, at their
election, as real parties in interest) in the defense of such Claim. Each of the
elections provided for in this Section 10 may be made separately by Owner and
Developer for each of their parcels. Notwithstanding the foregoing:
(1) Upon written notice to the City, Developer and/or Owner shall
have the right in their sole discretion to elect not to defend the City or elect
not to defend the validity of this Agreement. In said event, the electing party
shall be deemed to have consented to the termination of this Agreement as to
said party and City shall take all required actions as may be required by law or
by this Agreement to (A) settle the Claim and (B) terminate this Agreement as
to the electing party.
(2) Should any Indemnified Party fail to notify Owner and
Developer of the existence of any Claims or fail to fully cooperate with Owner
and Developer in the defense of any Claims, then Owner and Developer, as
appropriate, may elect to terminate their indemnification obligations under this
Section 10.f and if such an election is made in writing to the parties to this
Agreement, this Agreement shall terminate, expire and have no further force
or effect.
(3) The Indemnified Parties shall not reject any reasonable
settlement, including, without limitation, the option of not proceeding with
any project. Should any Indemnified Party reject a settlement which is
reasonably acceptable to Developer or Owner or their successors or assign,
Owner and Developer may elect to terminate their indemnification obligations
under this Section 10.f by written notice to all parties. If such an election is
Final: December 13, 1996 11086-00006 pt 1480121.4 -19-
made, said obligations shall, insofar as the rejecting Indemnified Party is
concerned, immediately terminate, expire and have no further force or effect
and the rejecting Indemnified Party shall thereafter be obligated to defend itself
against said Claims at its own cost and expense.
(4) If Owner or Developer are at any time required by this
Agreement to indemnify, defend, protect or hold any Indemnified Party
harmless from any Claims, then said Owner or Developer shall have the right
but not the obligation as to each separate parcel to terminate and cancel this
Agreement as it affects the portion of the Property owned by said terminating
party. If Owner or Developer elect to terminate this Agreement pursuant to
this Section 10.f.(4), it shall do so by written notice to the City and the other
party hereto, in which event this Agreement shall as to the applicable parcel
terminate, expire and have no further force or effect. Thereafter, the
terminating party's indemnity and defense obligations pursuant to this
Agreement shall, as to acts or omissions occurring after the effective date of
said termination, have no further force or effect.
11.Compliance; Termination, Modifications And Amendments.
a. Review Of Compliance.' The Director of Community Development of
the City ("Director") shall review this Development Agreement once each year, on or
before each anniversary of the Effective Date ("Periodic Review"), in accordance
with this Section I 1, the Applicable Rules and Resolution 90-52 of the City of
Temecula ("Resolution 90-52") in order to determine whether or not Developer and
Owner are out-of-compliance with any specific term or provision of this Agreement.
At commencement of each Periodic Review, the Director shall notify Developer and
Owner in writing that said Periodic Review is or has been commenced.
(1) Prima Facie Compliance- During each Periodic Review, the
Director shall request, in writing, that Developer and Owner each demonstrate
that they have during the preceding twelve (12) month period, been in prima
facie compliance with this Agreement. For purposes of this Agreement, the
phrase "prima facie compliance" shall mean that Developer and/or Owner have
demonstrated that it has acted in a commercially reasonable manner (taking
into account the circumstances which then exist) and in good faith in
attempting to adhere to the substance of this Agreement. Precise or technical
adherence to each term or provision of this Agreement shall not be required in
order for a party to be in prima facie compliance; and the failure of any party
to agree with the City in connection with the determination or implementation
of any Discretionary Approval, Future Approval or Ministerial Approval shall
not demonstrate a lack of prima facie compliance.
Final: December 13, 1996 11086-00006 pt 1480121.4 -20-
(2) Notice Of Non-CoMpliance-, Cure Rights. If during any
Periodic Review, the Director reasonably concludes that (A) either Developer
or Owner has not demonstrated that it is in prima facie compliance with this
Agreement, AND (B) that said party is out of compliance with a specific,
substantive term or provision of this Agreement, then the Director may issue
and deliver to that party a written "Notice of Non-compliance" detailing the
specific reasons for non-compliance (including references to sections and
provisions of this Agreement and Applicable Rules which allegedly have been
breached) with a complete statement of all facts demonstrating such non-
compliance. That party shall then have thirty (30) calendar days following
their receipt of the Notice of Non-compliance to cure said failure(s), provided,
however, if any one or more of the item(s) of non-compliance set forth in the
Notice of Non-compliance cannot reasonably be cured within said thirty(30)
calendar day period, then that party shall not be in breach of this Agreement if
it commences to cure said item(s) within said thirty (30) day period and
diligently prosecute said cure to completion. Upon completion of each
Periodic Review, the Director shall submit a report to the City Council setting
forth the Director's determination of whether or not each Owner and
Developer have satisfactorily demonstrated prima facie compliance with this
Development Agreement, and if not, what steps have been taken by the
Director or what steps he/she recommends that the City subsequently take. A
breach or default by one party shall not constitute a breach or default by the
other party.
b. Termination of Development Agreement As To Breaching Pariy. If
either Owner or Developer fails to timely cure any item(s) of non-compliance set
forth in a Notice of Non-compliance, then the City shall have the right but not the
obligation to initiate proceedings for the purpose to terminating this Agreement as
against that party or the legal remedies described in Paragraph 15 of this Agreement;
however, termination of this Agreement as to one party shall not ten-ninate this
Agreement as to any nonbreaching party. If the City determines to terminate this
Agreement as to any party, it shall give written notice thereof to both Developer and
Owner, which notice shall specify the precise grounds for termination and shall set a
date, time and place for a public hearing on the issue, all in compliance with the
Development Agreement Statutes. At the noticed public hearing, the breaching party
and/or its designated representative, as well as the non-breaching party and/or its
designated representatives, as well as the non-breaching party, shall be given an
opportunity to make a full and public presentation to the City. If, following the
taking of evidence and hearing of testimony at said public hearing, the City finds,
based upon substantial evidence, that the breaching party has not demonstrated prima
facie compliance with this Agreement, and that the breaching party is out of
compliance with a specific, substantive term or provision of this Agreement, then the
City may (unless the parties otherwise agree in writing) terminate this Agreement as
to that breaching party.
Final: December 13, 1996 11086-00006 pt 1480121.4 -21-
C. Modification or Amendment, of Deve]Mment Agreement.
Subject to the notice and hearing requirements of the applicable Development
Agreement Statutes, this Agreement may be modified or amended from time to time
only with the written consent of the Owner, Developer and the City or their
successors and assigns in accordance with the provisions of the Temecula Municipal
Code and Section 65868 of the Govenuncut Code, The parties contemplate arnending
this Agreement to refine the legal descriptions of the Developer's Parcels and
Owner's Parcel once a parcel map has been approved for the Property. Such an
amendment being contemplated by this Agreement may be approved by the City
Manager on behalf of the City without notice and hearing pursuant to Govenunent
Code Section 65867. Any changes to ffic legal description of the Property will
require compliance with Government Code Section 65867.
d. Termination of Devel%ment Agreement. Nothwitstanding
anything to the contrary contained in this Agreement, either Owner or Developer,
may, on or before commencement of construction to the Regional Center as described
in Section 7.c.(3) of this Agreement, terminate this Agreement by writen notice to all
parties, unless the non-tenninating party agrees to assume the terminating party's
rights and obligations under @ Agreement pursuant to Section 16 of @ Agreement.
12, Q2erating Memoranda, The provisions of this Agreement require a
close degree of cooperation between City, Developer and Owner. The anticipated
refinements to the Developer's Project and other development activity at the Property may
demonstrate that clarifications to this Agreement and the Applicable Rules are appropriate
with respect to the details of performance of City, Developer, and Owner, If and when,
from time to @e, during the term of this Agreement, City, Developer and Owner agree that
such clarifications are necessary or appropriate, they shall effectuate such clarifications
through operating memoranda approved in writing by the City, Developer and Owner,
which, after execution, shall be attached hereto and become a part of this Agreement and the
same may be further clarified from time to time as necessary with future written approval by
City, Developer and Owner. Operating memoranda are not intended to constitute an
amendment to this Agreement but mere ministerial clarifications, therefore public notices and
hearings shall not be required. The City Attorney shall be authorized, upon consultation
with, and approval of, Developer and Owner, to determine whether a requested clarification
may be effectuated pursuant to this Section or whether the requested clarification is of such a
character to constitute an amendment hereof which reqlims compliance with the provisions
of Section 12-c-, above. The authority to enter into such operating memoranda is hereby
delegated to the City Manager and the City Manager is hereby authorized to execute any
operating memoranda hereunder without further Council action.
13. Term of Ag@ement. This Agreement shall become operative and
commence upon the Effective Date. It shall remain in effect until ten (10) years from the
Effective Date unless this Agreement is terminated, modified, or extended upon mutual
written consent of the parties hereto or as otherwise provided in this Agreement. Following
Final: Dm=@ 13. 19% IIUWOM sK 1480121.d -22-
the expiration or termination of the term, hereof, this Agreement @ll br, d ted
and of no fudwr force and effert; provided, such expiration or termination 5hall not
automatically affect any right of the City, Developer or Owner arising from City approvals
on the Property prior to the expiration or termination of the term and arising from the duties
of tbc parties as prescribed in this Agreement.
Final; Dccombtr 13. 1996 It pt 1480121.4 -22A-
14. Tax Reimbursements. The Property lies within an area defined as
Mello-Roos Community Facilities District 88-12 ("CFD 88-12"). The City has entered into
certain sales tax reimbursement agreements with property owners in CFD 88-12 to help
offset the special taxes imposed by CFD 88-12. Subject to the specific ten-ns of the
agreements, the City agrees to implement any existing reimbursement agreements which may
be applicable to the Property and to Developer and Owner by virtue of their ownership of
portions of the Property.
15.Administration of Agreement and Resolution of Disputes.
a. Administration of Disputes. All disputes involving the enforcement,
interpretation or administration of this Agreement (including, but not limited to
decisions by the City staff concerning this Agreement and any of the projects or other
matters concerning this Agreement which are the subject hereof) shall first be subject
to good faith negotiations between the parties to resolve the dispute. In the event the
dispute is not resolved by negotiations, the dispute shall then be heard and decided by
the Planning Commission. Then, decisions of the Planning Commission which
remain in dispute shall be appealed to the City Council in accordance with the
procedures set forth in the Applicable Rules. Then, decisions of the City Council
which remain in dispute shall be appealable to, heard by, and resolved pursuant to the
Mandatory Alternative Dispute Resolution procedures set forth in Section 15.b
hereinbelow. Unless the dispute is resolved sooner, City shall use diligent efforts to
complete the foregoing Planning Commission and City council reviews within 30 days
of receiving a written notice of default or dispute notice. Nothing in this Agreement
shall prevent or delay Developer or Owner from seeking a temporary or preliminary
injunction in state or federal court if they believe that injunctive relief is necessary on
a more immediate basis.
b. MandatoKy Alternative Dispute Resolution. After the provisions of
Section 15.a above have been complied with, and pursuant to Code of Civil Procedure
Section 638. et seq., all disputes regarding the enforcement, interpretation of
administration of this Agreement (including, but not limited to, appeals from decisions
of the City Council, all matters involving Code of Civil Procedure Section 1094.5, all
Ministerial Approvals, Discretionary Approvals Future Approvals and the application
of Applicable Rules) shall be heard and resolved pursuant to the alternative dispute
resolution procedure set forth in this Section 15.b. All matters to be heard and
resolved pursuant to this Section 15.b shall be heard and resolved by a single
appointed referee who shall be a retired judge from either the California Superior
Court, the California Court of Appeal, the California Supreme Court, The United
States District Court or the United States Court of Appeals, provided that the
appointed referee shall have significant and recent experience in resolving land use
and real property disputes. The parties to this Agreement who are involved in the
dispute shall agree and appoint a single referee who shall then try all issues, whether
of fact or law, and report in writing to the parties to the disputes all findings of facts
Final: December 13, 1996 11086-00006 pt 1480121.4 -23-
and issues and decisions of law and the final judgments made thereon, in sufficient
detail to inform each party as the basis of the referee's decision. The referee shall try
all issues as if he/she were a California Superior Court judge, sitting without a jury,
and shall (unless otherwise limited by any term or provision of this Agreement) have
all legal and equitable powers granted a California Superior Court judge. Prior to the
hearing, the parties shall have full discovery rights as provided by the California Code
of Civil Procedure. At the hearing, the parties shall have the right to present
evidence, examine and cross-examine lay and expert witnesses, submit briefs and
have arguments of counsel heard, all in accordance with a briefing and hearing
schedule reasonably established by the referee. The referee shall be required to
follow and adhere to all laws, rules and regulations of the State of California in the
hearing of testimony, admission of evidence, conduct of discovery, issuance of a
judgment and fashioning of remedy, subject to such restriction on remedies as set
forth in this Agreement. If the parties involved in the dispute are unable to agree on
a referee, any party to the dispute may seek to have a single referee appointed by a
California Superior Court judge and the hearing shall be held in Riverside County
pursuant to Code of Civil Procedure Section 640. The cost of any proceeding held
pursuant to this Section 15.b shall initially be bome equally by the parties involved in
the dispute, and each party shall bear its own attorneys' fees. Any referee selected
pursuant to this Section shall be considered a temporary judge appointed pursuant to
Article 6, Section 21 of the California Constitution. If any party to the dispute fails
to timely pay its fees or costs, or fails to cooperate in the administration of the
hearing and decision process as determined by the referee, the referee shall upon the
written request of any party to the dispute be required to issue a written notice of
breach to the defaulting party and, if the defaulting party fails to timely respond or
cooperate with the period of time set forth in the notice of default (which in any event
may not exceed thirty (30) calendar days), then the referee shall upon the request of
any non-defaulting party render a default judgment against the defaulting party. At
the end of the hearing, the referee shall issue a written judgment (which may include
an award of reasonable attorneys' fees and costs as elsewhere provided in this
Agreement), which judgment shall be final and binding between the parties and may
be entered as a final judgment in a California Superior Court. The referee shall use
his/her best efforts to finally resolve the dispute and issue a final judgment within
sixty (60) calendar days from his/her appointment.
(1) Any party to the dispute may, in addition to any other rights or
remedies provided to it by this Agreement, seek, to enjoin any threatened or
attempted violation hereof, or enforce by specific performance the obligations
and rights of the parties hereto, except as otherwise provided herein.
(2) The parties hereto agree that (A) the City would not have
entered into this Agreement if it were to be liable for general, special or
compensatory damages for any default under or with respect to this Agreement
or the application thereof, and (B) Owner and Developer have adequate
Final: December 13, 1996 1108 pt 1480121.4 -24-
remedies, other dm general, special or compensatory damages, to S=rc
City's compliance with its obligations under this Agreement. Therefore, the
undersigned agree that the City, and its officers, employees and agents, shall
not be liable for general, special or compensatory damages to the Owner
Developer or to any successor or assignee or transferee of the Owner or
Developer, for the City's breach or default under or with respect to @
Agreement; and @ Owner and Developer cove@ not to sue the City for, or
claim against the City, any right to receive general, special or compensatory
damages for default of this Ag@ent by City. Nondthstanding the
provisions of this subsection (2), City agrees that Developer and Owner shall
have the right to seek a refund or return of a deposit made with the City or fee
paid to the City in accordance with the provisions of the Applicable Rules.
(3) The City agrees that (A) the Owner and Developer would not
have entered into tWs Agreement if either were to be liable for general, special
or compensatory damages for any default under or with respect to this
Agree=nt or the application thereof, W (B) City, has adequate r@ies,
other than general, special or compensatory damages, to secure Owners's and
Developer's compliance with their respective obligations under this
Agreement. Therefore, the City agrees that the Owner aW Developer, and
their officers, employees and agents, shall not be liable for general. V=ial or
compensatory damages to the City or to any successor or assig= or
transferee of Om City, for the Owner's or Devek)per's breach or deftwt under
or with respect to this Agrftmnt; and the City covenants not to sue the
Owner or @veloper for, or claim against the Owner or Developer, any right
to receive general, special or compensatory damages for default of ffik
Agreement by City. Notwithstanding the other provisions of @ Section to
the Contrary, City agrees that its ordy recourse in the event the Developer, or
Owner, as applicable, does not proceed with co on of the Regional
Center as provided in Section 8., @ll be the termination of this Development
Agreement in accordance with Section II above, and, without limiting the
foregoing, City shall not have any right to damages or speciric enforcement of
dw Developer's obligation to complete @ Regional Center as provided in
Smtion S; provided, however, d= this paragraph @ nm limit City's right to
@ifically enforce condifions and requirements of the Applicable Rules which
are applicable to development actually urwertakcn by Developer or Owner.
16.Trgpsfers and Assignmf!nts
a. Right to Assizn. Developer or Owner shall have the right to sell,
assign or transfer all or portions of the Property and the rights under this Agreement
which they inay own to any person at any time during the term of this Agreement
without approval of the City provided Developer has provided to Owner and to the
City Manager @ (30) days prior written notice of the proposed transfer and
1.1.19% 130 pt 14MI21.4 -25-
Developer provides to Owner aW City with notire of the name aW address of the
assign= within ten (10) days of the effective date of the @er. StioWd the Owner
acquire the rights of the Developer (as elsewhere provided in this Agreement), the
Owner shall have the right to sell, assign or transfer the rights under this Agreement
without the approval of dw City provided the Owner has provided to the City
Manager thirty (30) days prior written notice of the proposed @fer aW the namc
and address of the assignee within ten (10) days after the effective date of the
transfer.
13, IM I I pt 1440121.4 -25A-
b. Liabilities Upon Transfer. Upon the delegation of all duties and
obligations and the sale, transfer or assignment of all or any portion of the Property,
Developer or Owner, as the case may be, shall be released from its obligations under
this Agreement with respect to the Property, or portion thereof, so transferred arising
subsequent to the effective date of such transfer if (1) Developer has provided to
Owner and City thirty (30) days' prior written notice of such transfer (2) the
transferee has agreed in writing to be subject to all of the provisions hereof applicable
to the portion of the Property so transferred. Upon any transfer of any portion of the
Property and the express assumption of Developer's or Owner's obligations under this
Agreement by such transferee, City agrees to look solely to the transferee for
compliance by such transferee with the provisions of this Agreement as such
provisions relate to the portion of the Property acquired by such transferee. Any such
transferee shall be entitled to the benefits of this Agreement and subject to the
obligations of this Agreement, applicable to the parcel(s) transferred. A default by
any transferee shall only affect that portion of the Property owned by such transferee
and shall not cancel or diminish in any way Developer's or Owner's rights hereunder
with respect to any portion of the Property not owned by such transferee. The
transferee shall be responsible for the reporting and annual review requirements
relating to the portion of the Property owned by such transferee, and any amendment
to this Agreement between City and a transferee shall only affect the portion of the
Property owned by such transferee.
C. Owner's Rijzhts. In the event Developer does not purchase one or both
of the Developer's Parcels and its right to do so expires or terminates, the Owner's
rights with respect to such Developer's Parcels are set forth at Section 3 of this
Agreement.
17. Mortizaize Protection. The parties hereto agree that this Agreement
shall not prevent or limit Developer or Owner, in any manner, at Developer's or Owner's
sole discretion, from encumbering the Property or any portion thereof or any improvement
thereon by any mortgage, deed of trust or other security device securing financing with
respect to the Property. City acknowledges that the lender(s) providing such financing may
require certain Agreement interpretations and modifications and agrees upon request, from
time to time, to meet with Developer or Owner and representatives of such lender(s) to
negotiate in good faith any such request for interpretation or modification. City will not
unreasonably withhold its consent to any such requested interpretation or modification
provided such interpretation or modification is consistent with the intent and purposes of this
Agreement. Any mortgagee of a mortgage or a beneficiary of a deed of trust ("Mortgagee")
on the Property shall be entitled to the following rights and privileges:
a. Mortgage Not Rendered Invalid. Neither entering into this
Agreement nor a breach of this Agreement shall defeat, render invalid, diminish, or
impair the lien of any mortgage or deed of trust on the Property made in good faith
and for value.
Final: December 13, 1996 11086-00006 pt 1480121.4 -26-
b. Request for Notice to Mortizaizee. The Mortgagee of any mortgage or
deed of trust encumbering the Property, or any part thereof, who has submitted a
request in writing to City in the manner specified herein for giving notices, shall be
entitled to receive written notification from City of any default by Developer or
Owner in the performance of Developer's or Owner's obligations under this
Agreement.
C. Mortiza2ee's Time to Cure. If City timely receives a request from a
Mortgagee requesting a copy of any notice of default given to Developer under the
terms of this Agreement, City shall provide a copy of that notice to the Mortgagee
within ten (10) days of sending the notice of default to Developer or Owner. The
Mortgagee shall have the right, but not the obligation, to cure the default during the
remaining cure period allowed such party under this Agreement.
d. PropeM Taken Subject to Obligations. Any Mortgagee who comes
into possession of the Property, or any part thereof, pursuant to foreclosure of the
mortgage or deed of trust, or deed in lieu of foreclosure, shall take the Property, or
part thereof, subject to the terms of this Agreement; provided, however, in no event
shall such Mortgagee be liable for any defaults or monetary obligations of Developer
arising prior to acquisition of title to the Property by such Mortgagee, except that any
such Mortgagee or its successors or assigns shall not be entitled to a building permit
or occupancy certificate until all delinquent and current fees and other monetary
obligations due under this Agreement for the Property, or portion thereof acquired by
such Mortgagee, have been paid to City.
18. Notices. All notices under this Agreement shall be in writing and shall
be deemed delivered when personally received by the addressee, or within three (3) calendar
days after deposit in the United States mail by registered or certified mail, postage prepaid,
return receipt requested, to the following parties and their counsel at the addresses indicated
below, provided, however, if any party to this Agreement delivers a notice or causes a notice
to be delivered to any other party to this Agreement, a duplicate of that Notice shall be
concurrently delivered to each other party and their respective counsel.
To City:City of Temecula
Attention: City Manager
43200 Business Park Drive
Temecula, CA 92590-3606
With a Copy to:Peter M. Thorson, Esq.
Richards, Watson & Gershon
333 South Hope Street, 38th Floor
Los Angeles, CA 90071
Final: December 13, 1996 1108 6 pt 1480121.4 -27-
To Developer:Forest City Development Inc.
949 South Hope Street, Suite 200
Los Angeles, CA 90015
Attn:Brian M. Jones
With a Copy to: Forest City Enterprises, Inc.
10800 Brookpark Rd.
Cleveland, Ohio 44130
Attention:General Counsel
To Owner:LGA-7, INC.
c/o Kemper Insurance Companies
One Kemper Drive
Corporate Legal Department, C-3
Long Grove, Illinois, 60049-0001
Attn:Chief Financial Officer and
General Counsel
With a Copy to:Myron Meyers, Esq.
Keith D. Elkins, Esq.
Jeffers, Mangels, Butler & Marrnaro,
LLP
2121 Avenue of the Stars, 10th
Floor
Los Angeles, California 90067
With a Copy to:Heitman Capital Management Company
9601 Wilshire BI., Suite 200
Beverly Hill, California 90211
Attention: Mr. Brett Mayer
Notice given in any other manner shall be effective when received by the addressee. The
addresses for notices may be changed by notice given in accordance with this provision.
19. Severability and Termination. If any provision of this Agreement is
determined by a court of competent jurisdiction to be invalid or unenforceable, or if any
provision of this Agreement is superseded or rendered unenforceable according to any law
which becomes effective after the Effective Date, the remainder of this Agreement shall be
Final: December 13, 1996 11086-00006 pt 1480121.4 -28-
effective to the extent the remaining provisions are not rendered impractical to perform,
taking into consideration the purposes of this Agreement.
20. Time of Essence. Time is of the essence for each provision of this
Agreement of which time is an element.
21. Force Majeure. Changed conditions, changes in local, state or federal
laws or regulations, floods, earthquakes, delays due to strikes or other labor problems,
moratoria enacted by City or by any other governmental entity or agency, injunctions issued
by any court of competent jurisdiction, the inability to obtain materials, civil conimotion,
fire, intragalatic invasion, acts of God, or other circumstances which substantially interferes
with the development or construction of the Developer's Parcels or the development of the
Owner's Parcel, or which substantially interferes with the ability of any of the parties to
perform its obligations under this Agreement shall collectively be referred to as "Events of
Force Majeure. " If any party to this Agreement is prevented by an Event or Events of Force
Majeure from performing its obligation under this Agreement, then on condition that the
party claiming the benefit of said Event(s) of Force Majeure (a) did not cause said Event(s)
and (b) said Event(s) was beyond said party's reasonable control, the time for performance
by said party of its obligations under this Agreement shall be extended by a number of days
equal to the number of days that said Event(s) of Force Majeure continued in effect, or by
the number of days it takes to repair or restore the damage caused by said Event(s) to the
condition which existed prior to the occupance of said Event(s), which ever is longer;
provided, however, that the termination date of this Agreement as set forth in Section 13 of
this Agreement shall not be extended by this provision.
22. Waiver. No waiver of any provision of this Agreement shall be
effective unless in writing and signed by a duly authorized representative of the party against
whom enforcement of a waiver is sought.
23. No Third Party Beneficiaries. This Agreement is made and entered
into for the sole protection and benefit of the Developer, Owner, the City of Temecula and
their successors and assigns. No other person shall have any right of action based upon any
provision of this Agreement.
24. Attorneys' Fees. If any party commences any action for the
interpretation, enforcement, termination, cancellation or rescission of this Agreement, or for
specific performance for the breach hereof, the prevailing party shall be entitled to its
reasonable attorneys' fees, litigation expenses and costs. Attorneys' fees under this Section
shall include attorneys' fees on any appeal as well as any attorneys' fees incurred in any
post-judgment proceedings to collect or enforce the judgment.
25. Incol:poration of Exhibits. The following exhibits which are part of this
Agreement are attached hereto and each of which is incorporated herein by this reference as
though set forth in ftill:
Final: December 13, 1996 11086-00006 pt 1480121.4 -29-
EXHIBIT ALEGAL DESCRIPTION
Exhibit A-1Property
Exhibit A-2Developer's Parcels--Mall Parcel
Exhibit A-3Developer's Parcels--Power Center Parcel
Exhibit A-4Owner's Parcel
EXHIBIT B CITY OF TEMECULA FURNISHED
INFRASTRUCTURE
Exhibit B-1 Street Improvements
Exhibit B-2 Traffic Signals
Exhibit B-3 Underground Power Lines
Exhibit B-4 Storm Drain Improvements
26. Authority to Execute; Binding Effect. Owner and Developer each
represent and warrant that they have the power and authority to execute this Agreement and,
once executed, this Agreement shall be final and binding on said parties. The City
represents and warrants to Owner and Developer as follows: (a) all public notices have been
given and published, all public hearings have been held, all applicable laws, rules,
ordinances and regulations have been issued as are necessary or required for the approval of
this Agreement; (b) this Agreement is consistent with Specific Plan 263; (c) this Agreement
once executed by the City, shall be final and binding on the City; and (d) this Agreement
may not be amended, modified, changed or terminated in the future by the City except in
accordance with the terms and conditions set forth herein.
27. Entire Agreement; Conflicts. This Agreement represents the entire
agreement of the parties. This Agreement integrates all of the terms and conditions
mentioned herein or incidental hereto, and supersedes all negotiations or previous agreements
between the parties or their predecessors in interest with respect to all or any part of the
subject matter hereof. Should any or all of the provisions of this Agreement be found to be
in conflict with any other provision or provisions found in the Applicable Rules, or
Subsequent Applicable Rules, then the provisions of this Agreement shall prevail.
IN WITNESS WHEREOF, the Parties have each executed this Agreement of
the date first written above.
CITY OF TEMECULA
By:
KAREL LINDEMANS
Mayor
Final: December 13, 1996 11086-00006 pt 1480121.4 -30-
ATTEST:
June S. Greek
City Clerk
APPROVED AS TO FORM:
Peter M. Thorsofi
City Attorney
Final: December 13, 1996 11086@6 pt 1480121.4 -31-
FROM JEFF---R, A. (MON) 2. 1 :4'@/ ST. 7: 4",-", NO. P 2
FOREST CrrY DEvELOpMFNT
CALMORN'LA, INC.,
a Cali on
B
President
By-
LGA-7, INC-, an Iglinois Corporation
By:
BY;
Pt 14MI21.4 -32-
CALIFORNIA
ALL-PURPOSIE],
ACKNOWLEDGEMENT
STATE OF CALIFORNIA
C 0 U N T Y 0 F@
On @before me, C-
DATE NAME, TIT[ @ OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC"
personally appeared,
personally known to me (or proved to me on the basis of satisfactory evidence) to be the person(*
whose namew is/ai:e subscribed to the within instrument and acknowledged to me that he/@/
@ executed the same in his/@/@r authorized capacity@, and that by his/
signature@n the instrument the person(@, or the entity upon behalf of which the person(*acted,
executed the instrument.
WITNESS my hand and official seal.
PAUL PRATT
8 Anloom
(S AL)
NOTARY PUSIGNATU@@
OPTIONAL INFORMATION
TITLE OR TYPE OF
DATE OF DOCUME NUMBE F PAGES
SIGNER(S) OTHER THAN NAMED ABO@
LGA-7, Inc., an Illinois corporation
By: A, -,@ @
,/ Jc*m K. Con
I
Its. QIcretary
O'\
By:
D id M. Steirer
Its:Vice President
STATE OF ILLINOIS
COUNTYOF Clet-@@
I hereby certify that on this day, before me, an officer duly authorized to administer
oaths and take acknowledgments, personally appeared John K. Conway, known to me
to be the Secretary of LGA-7, Inc., and David M. Steirer, known to me to be the Vice
President of LGA -7 Inc., each of whom acknowledged to me that he subscribed to the
within instrument in his authorized capacity, and that by his signature on the instrument
executed the same freely and voluntarily, under authority duly vested in him by said
corporation.
Witness my hand and official seal.
'Not@ Signature
ALSEAL"
e Lakowski
State of iiijnoi!
ri Ex@)ires ,,lz4l9 (k) u Iz: /- IA-@ Z
Printed Notary Signature
EXHIBIT A-1
LEGAL DESCRIPTION
FOR DEVELOPMENT AGREEMEENT DV96-000_
PROPERTY:
FinW: December 12. 19% 1108 pi 1480121.3 -36-
Robert Bein, William Frost & Associates
27555 Ynez Road, Suite 400
Temecula, CA 92591
EXHIBIT "A" December 3, 1996
JN 401027-M5
LEGAL DESCRIPTION Page 1 of I
MALL SITE
OVERALL OWNERSHIP
That certain parcel of land situated in the City of Temecula, County of Riverside, State of
California, being those portions of Lots 115, 117, 140 and 141, Jackson Avenue, Lincoln
Avenue and Monroe Avenue (vacated by Resolution of the Board of Supervisors recorded
December 19, 1951 in Book 1328, Page 67 of Official Records in the Office of the County
Recorder of said Riverside County) and Apricot Street as shown on a Map of the Temecula
Land and Water Company filed in Book 8, Page 359 of Maps in the Office of the County
Recorder of San Diego County, California, together with those portions of Lots 4 through 7
of Tract No. 3334 filed in Book 54, Pages 25 through 30 of Maps in said Office of the Riverside
County Recorder, included within Parcels A, B, C, F, G and H of Lot Line Adjustment No.
PA95-0111 recorded December 15, 1995 as Instrument No. 416771 of Official Records in said
Office of the Riverside County Recorder.
CONTAINING: 189.17 Acres Gross, more or less.
SUBJECT TO all covenants, rights, rights-of-way and easements of record.
Lawrence L. Bacon, PLS 3527
CL
w
tv LIJ Z x
ul
iu
>
m
w
>
0cn
to
EXHIBIT A-2
LEGAL DESCRIPTION
FOR DEVELOPM[ENT AGREEMENT DV96-000_
DEVELOPER'S PARCELS--MALL PARCEL
Final: December 12. 19% 110 pt 1480121.3 -37-
Robert Bein, William Frost & Associates
27555 Ynez Road, Suite 400
Temecula, CA 92591
Revised December 3, 1996
November 5, 1996
JN 401027-M3
Page I of 4
EXHIBIT "A"
LEGAL DESCRIPTION
TEMECULA TOWN CENTER
WESTERLY PORTION - REGIONAL MALL
That certain parcel of land situated in the City of Temecula, County of Riverside, State of
California, being those portions of Lots 115, 117, and 140, Jackson Avenue and Monroe
Avenue (vacated by Resolution of the Board of Supervisors recorded December 19, 1951 in
Book 1328, Page 67 of Official Records in the Office of the County Recorder of said Riverside
County) and Apricot Street as shown on a map of the Temecula Land and Water Company
filed in Book 8, Page 359 of Maps in the Office of the County Recorder of San Diego County,
California, together with those portions of Lots 4, 5 and 6 of Tract No. 3334 filed in Book 54,
Pages 25 through 30 of Maps in said Office of the Riverside County Recorder (being also
shown as portions of Parcels A, B, F, G and H of Lot Line Adjustment No. PA95-0111
recorded December 15, 1995 as Instrument No. 416771 of Official Records in said Office of
the Riverside County Recorder, described as a whole as follows:
COMMENCING at the intersection of the centerline of Margarita Road (110.00 feet wide)
as described in Parcel 1 of an easement deed recorded August 18, 1992 as Instrument No.
305607 of Official Records in said Office of the Riverside County Recorder with the
southeasterly line of Winchester Road (60.00 feet wide) as described in a deed recorded April
8, 1930 in Book 722, Page 512 of Deeds in said Office of the Riverside County Recorder;
thence along said centerline of Margarita Road through the following courses:
South 43'54'46" East 54.68 feet to the beginning of a tangent curve in said centerline concave
southwesterly and having a radius of 2000.00 feet;
thence along said curve southeasterly 931.03 feet through a central angle of 26040'19" to the
southerly ter-minus thereof;
thence leaving said centerline, radially from said curve South 72'45'33" West 55.00 feet;
thence South 53'33'19" West 844.53 feet to the TRUE POINT OF BEGINNING;
Revised December 3, 1996
Robert Bein William Frost & Associates November 5,1996
Temecula Town Center JN 401027-M3
Regional Mall - Westerly Portion Page 2 of 4
thence South 41'46'24" East 486.00 feet to the beginning of a tangent curve concave
southwesterly and having a radius of 350.00 feet;
thence along said curve southeasterly 231.36 feet through a central angle of 37'52'29";
thence tangent from said curve South 03053'55" East 180.01 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 350.00 feet;
thence along said curve southwesterly 318.42 feet through a central angle of 52'07'31";
thence tangent from said curve South 48'13'36" West 1072.28 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 394.00 feet;
thence along said curve southwesterly 171.91 feet through a central angle of 25'00'00";
thence tangent from said curve South 73'13'36" West 138.88 feet to the beginning of a tangent
curve concave northerly and having a radius of 394.00 feet;
thence along said curve westerly 309.45 feet through a central angle of 45'00'00";
thence tangent from said curve North 61'46'24" West 136.59 feet to the beginning of a tangent
curve concave southerly and having a radius of 35.00 feet;
thence along said curve westerly 54.98 feet through a central angle of 90'00'00";
thence tangent from said curve South 28'13'36" West 42.03 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 281.00 feet;
thence along said curve southwesterly 166.90 feet through a central angle of 34'01'48";
thence tangent from said curve South 62'15'24" West 112.31 feet to the beginning of a tangent
curve concave southeasterly and having a radius of 35.00 feet;
thence along said curve southwesterly 41.72 feet through a central angle of 68'18'02" to the
non-tangent intersection with a curve concave southwesterly and having a radius of 1267.00
feet in the northeasterly line of Ynez Road as described in a document recorded August 28,
1991 as Instrument No. 297822 of Official Records in said Office of the Riverside County
Recorder, a radial line of said curve from said point bears
South 64'10'44" West;
Revised December 3, 1996
Robert Bein William Frost & Associates November 5, 1996
Temecula Town Center JN 401027-M3
Regional Mall - Westerly Portion Page 3 of 4
thence non-tangent from said curve South 64'14'07" West 15.06 feet to the non-tangent
intersection with a curve concave southwesterly and having a radius of 1044.00 feet in the
northeasterly line of Ynez Road (88.00 feet wide) as described in a deed recorded July 12, 1973
as Instrument No. 90991 of Official Records in said Office of the Riverside County Recorder,
a radial line of said curve from said point bears South 64'14'07" West;
thence along said northeasterly line through the following courses: along said curve
northwesterly 295.80 feet through a central angle of 16'14'02";
thence tangent from said curve North 41'59'55" West 1143.31 feet to the be g of a tangent
curve concave easterly and having a radius of 50.00 feet;
thence along said curve northerly 78.65 feet through a central angle of 90'07'31" to the point
of tangency with said southeasterly line of Winchester Road (60.00 feet wide) as described in
said deed recorded April 8, 1930 in Book 722, Page 512 of Deeds;
thence leaving said northeasterly line, along said southeasterly line of Winchester Road
North 48'07'36" East 2409.53 feet;
thence South 41'52'24" East 50.i6 feet to a non-tangent intersection with a curve in the
southeasterly line of Winchester Road concave southeasterly and having a radius of 1933.00
feet, said point being the beginning of a non-tangent curve concave easterly and having a radius
of 35.00 feet, a radial line of last said curve from said point bears South 83'42'51" East;
thence along said curve southerly 29.36 feet through a central angle of 48'03'33";
thence tangent from said curve South 41'46'24" East 66.99 feet to the beginning of a tangent
curve concave westerly and having a radius of 260.00 feet;
thence along said curve southerly 174.08 feet through a central angle of 38'21'42";
thence tangent from said curve South 03'24'42" East 111.87 feet to the beginning of a tangent
curve concave northeasterly and having a radius of 35.00 feet;
thence along said curve southerly 48.73 feet through a central angle of 79'46'18" to a point of
reverse curvature with a curve concave southerly and having a radius of 500.00 feet, a radial
line of said curve from said point bears South 06'49'00" West;
Revised December 3, 1996
Robert Bein William Frost & Associates November 5, 1996
Temecula Town Center JN 401027-M3
Regional MaU - Westerly Portion Page 4 of 4
thence along said curve easterly 361.37 feet through a central angle of 41'24'36";
thence tangent from said curve South 41'46'24" East 205.91 feet to the TRUE POINT OF
BEGINNING.
CONTAINING:102.20 Acres Gross, more or less.
99.36 Acres Net, more or less.
SUBJECT TO all covenants, rights, rights-of-way and easements of record.
Lawrence L. Bacon, PLS 3527
cn
i
m
>
m
m
X
EXHIBIT A-3
LEGAL DESCRIPTION
FOR DEVELOPM[ENT AGREEMIENT DV96-000_
DEVELOPER'S PARCELS--POWER CENTER PARCEL:
FirW: Deccmbcr 12. 19% 1 10 Pt 1480121.3 -38-
Robert Bein, William Frost & Associates
27555 Ynez Road, Suite 400
Temecula, CA 92591
Revised December 3, 1996
November 5, 1996
JN 401027-M2
Page I of 3
EXHIBIT "A"
LEGAL DESCRIPTION
TEMECULA TOWN CENTER
REGIONAL MALL - POWER CENTER
That certain parcel of land situated in the City of Temecula, County of Riverside, State of
California, being those portions of Lots 140 and 141 and Lincoln Avenue (vacated by
Resolution of the Board of Supervisors recorded December 19, 1951 in Book 1328, Page 67
of Official Records in the Office of the County Recorder of said Riverside County) as shown
on a map of the Temecula Land and Water Company filed in Book 8, Page 359 of Maps in the
Office of the County Recorder of San Diego County, California (being also shown as Portions
of Parcels B and C of Lot Line Adjustment No. PA95-01 11 recorded December 15, 1995 as
Instrument No. 416771 of Official Records in said Office of the Riverside County Recorder)
described as a whole as follows:
BEGINNING at the intersection of the centerline of Margarita Road (110.00 feet wide) as
described in Parcel 1 of an easement deed recorded August 18, 1992 as Instrument No. 305607
of Official Records in said Office of the Riverside County Recorder with the southeasterly fine
of Winchester Road (60.00 feet wide) as described in a deed recorded April 8, 1930 in Book
722, Page 512 of Deeds in said Office of the Riverside County Recorder;
thence along said centerline of Margarita Road through the following courses:
South 43'54'46" East 54.68 feet to the beginning of a tangent curve in said centerline concave
southwesterly and having a radius of 2000.00 feet;
thence along said curve southeasterly 931.03 feet through a central angle of 26'40'19" to the
southerly terminus thereof; -
thence leaving said centerline, radially from said curve South 72'45'33" West 55.00 feet,
thence South 53'33'19" West 844.53 feet;
thence North 41'46'24" West 205.91 feet to the beginning of a tangent curve concave
southwesterly and having a radius of 500.00 feet;
Revised December 3, 1996
Robert Bein, William Frost & Associates November 5, 1996
Temecula Town Center Regional Mall JN 401027-M2
Power Center Page 2 of 3
thence along said curve northwesterly 361.37 feet through a central angle of 41'24'36" to a
point of reverse curvature with a curve concave northeasterly and having a radius of 35.00 feet,
a radial line of said curve from said point bears North 06'49'00" East;
thence along said curve northwesterly 48.73 feet through a central angle of 79'46'18";
thence tangent from said curve North 03'24'42" West 111.87 feet to the beginning of a tangent
curve concave westerly and having a radius of 260.00 feet;
thence along said curve northerly 174.08 feet through a central angle of 38'21'42";
thence tangent from said curve North 41'46'24" West 66.99 feet to the beginning of a tangent
curve concave easterly and having a radius of 35.00 feet;
thence along said curve northerly 29.36 feet through a central angle of 48'03'33" to the non-
tangent intersection with a curve concave southeasterly and having a radius of 1933.00 feet in
the southeasterly line of Winchester Road as described in a document recorded April 23, 1991
as Instrument No. 132834 of Official Records in said Office of the Riverside County Recorder,
a radial line of said curve from said point bears South 35'11'03" East;
thence non-tangent from said curve North 41'52'24" West 50.16 feet to said southeasterly line
of Winchester Road (60.00 feet wide);
thence along said southeasterly line through the following courses: North 48007'36" East 3.29
feet to the beginning of a tangent curve therein concave southeasterly and having a radius of
925.37 feet;
thence along said curve northeasterly 233.45 feet through a central angle of 14'27'16";
thence tangent from said curve North 62'34'52" East 269.57 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 985.37 feet;
thence along said curve northeasterly 283.66 feet through a central angle of 16'29'38";
Revised December 3, 1996
Robert Bein, William Frost & Associates November 5, 1996
Temecula Town Center Regional Mall JN 401027-M2
Power Center Page 3 of 3
thence tangent from said curve North 46'05'14" East 280.78 feet to the POINT OF
BEGINNING.
CONTAINING:22.81 Acres Gross, more or less.
20.64 Acres Net, more or less.
SUBJECT TO all covenants, rights, rights-of-way and easements of record.
Lawrence L. Bacon, PLS 3527
co
LLI X
@ X
Z UJ
LLI w
u LU
>
0 m
a-
I Cl)
C-4
EXHIEBIT A-4
LEGAL DESC@ION
FOR DEVELOPMENT AGREEMIENT DV96-000_
OV,INER'S PARCEL:
FinW: December 12. 19% 1108 pt 1480121.3 -39-
Robert Bein, William Frost & Associates
27555 Ynez Road, Suite 400
Temecula, CA 92591
December 3, 1996
JN 401027-M4
Page I of 4
EXHIBIT "A"
1,F,GAT, DESCRIPTION
TEMECULA TOWN CEH=R
LUMBERMAN PAR@
That certain parcel of land situated in the City of Temecula, County of Riverside, State of
California, being those portions of Lots 115, 117, 140, 141, Lincoln Avenue and Monroe
Avenue (vacated by Resolution of the Board of Supervisors recorded December 19, 1951 in
Book 1328, Page 67 of Official Records in the Office of the County Recorder of said Riverside
County) and Apricot Street as shown on a Map of the Temecula Land and Water Company
filed in Book 8, Page 359 of Maps in the Office of the County Recorder of San Diego County,
California, together with those portions of Lots 4, 5 and 6 of Tract No. 3334 filed in Book 54,
Pages 25 through 30 of Maps in said Office of the Riverside County Recorder (being also
shown as portions of Parcels A, B, C, F, G and H of Lot Line Adjustment No. PA95-0111
recorded December 15, 1995 as Instrument No. 416771 of Official Records in said Office of
the Riverside County Recorder, described as a whole as follows:
COMMENCING at the intersection of the centerline of Margarita Road (110.00 feet wide)
as described in Parcel 1 of an easement deed recorded August 18, 1992 as Instrument No.
305607 of Official Records in said Office of the Riverside County Recorder with the
southeasterly line of Winchester Road (60.00 feet wide) as described in a deed recorded April
8, 1930 in Book 722, Page 512 of Deeds in said Office of the Riverside County Recorder;
thence along said centerline of Margarita Road through the following courses:
South 43'54'46" East 54.68 feet to the beginning of a tangent curve in said centerline concave
southwesterly and having a radius of 2000.00 feet;
thence along said curve southeasterly 931.03 feet through a central angle of 26'40'19" to the
southerly terminus thereof and the TRUE POINT OF BEGINNING;
thence leaving said centerline, radially from said curve South 72'45'33" West 55.00 feet;
thence South 53'33'19" West 844.53 feet;
thence South 41'46'24" East 486.00 feet to the beginning of a tangent curve concave
southwesterly and having a radius of 350.00 feet;
Robert Bein William Frost & Associates December 3, 1996
Temecula Town Center Regional Mall JN 401027-M4
Lumberman Parcel Page 2 of 4
thence along said curve southeasterly 231.36 feet through a central angle of 37'52'29";
thence tangent from said curve South 03'53'55" East 180.01 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 350.00 feet;
thence along said curve southwesterly 318.42 feet through a central angle of 52'07'31";
thence tangent from said curve South 48'13'36" West 1072.28 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 394.00 feet;
thence along said curve southwesterly 171.91 feet through a central angle of 25'00'00";
thence tangent from said curve South 73'13'36" West 138.88 feet to the be g of a tangent
curve concave northerly and having a radius of 394.00 feet;
thence along said curve westerly 309.45 feet through a central angle of 45'00'00";
thence tangent from said curve North 61'46'24" West 136.59 feet to the beginning of a tangent
curve concave southerly and having a radius of 35.00 feet;
thence along said curve westerly 54.98 feet through a central angle of 90'00'00";
thence tangent from said curve South 28'13'36" West 42.03 feet to the beginning of a tangent
curve concave northwesterly and having a radius of 281.00 feet;
thence along said curve southwesterly 166.90 feet through a central angle of 34'01'48";
thence tangent from said curve South 62'15'24" West 112.31 feet to the beginning of a tangent
curve concave southeasterly and having a radius of 35.00 feet;
thence along said curve southwesterly 41.72 feet through a central angle of 68'18'02" to the
non-tangent intersection with a curve concave southwesterly and having a radius of 1267.00
feet in the northeasterly line of Ynez Road as described in a document recorded August 28,
1991 as Instrument No. 297822 of Official Records in said Office of the Riverside County
Recorder, a radial line of said curve from said point bears
South 64010'44" West;
thence non-tangent from said curve South 64'14'07" West 15.06 feet to the non-tangent
intersection with a curve concave southwesterly and having a radius of 1044.00 feet in the
northeasterly line of Ynez Road (88.00 feet wide) as described in a deed recorded July 12, 1973
as Instrument No. 90991 of Official Records in said Office of the Riverside County Recorder,
Robert Bein William Frost & Associates December 3, 1996
Temecula Town Center Regional Mail JN 401027-M4
Lumberman Parcel Page 3 of 4
a radial line of said curve from said point bears South 64'14'07" West;
thence along said northeasterly line and curve southeasterly 283.28 feet through a central angle
of 15'32'48";
thence South 10'13'05" East 15.06 feet to the northwesterly line of said Tract No. 3334;
thence along said northwesterly line South 44054'58" West 53.63 feet to the centerline of Ynez
Road as shown on said map of Tract No. 3334;
thence along said centerline South 10013'05" East 265.57 feet to the centerline of Proposed
Overland Drive as shown on said Lot Line Adjustment No. 95-0111;
thence along said centerline through the following courses: North 79'46'55" East 90.00 feet to
the beginning of a tangent curve concave southerly and having a radius of 1000.00 feet;
thence along said curve easterly 261.80 feet through a central angle of 15"00'00",
thence tangent from said curve South 85'13'05" East 683.49 feet to the beginning of a tangent
curve concave northerly and having a radius of 1000.00 feet;
thence along said curve easterly 117.80 feet through a central angle of 06044'57";
thence tangent from said curve North 88'01'58" East 546.33 feet to said centerline of Margarita
Road;
thence leaving said centerline of Overland Drive, along said centerline of Margarita Road
through the following courses: North 01'58'41" West 9.71 feet to the beginning of a tangent
curve concave easterly and having a radius of 2000.00 feet;
thence along said curve northerly 986.99 feet through a central angle of 28'16'31";
thence tangent from said curve North 26'17'50" East 479.08 feet to the beginning of a tangent
curve concave westerly and having a radius of 2000.00 feet;
Robert Bein William Frost & Associates December 3, 1996
Temecula Town Center Regional Mall JN. 401027-M4
Lumberman Parcel Page 4 of 4
thence along said curve northerly 1519.75 feet through a central angle of 43032'179P ;
thence tangent from said curve North 17'14'27" West 293.55 feet to the TRUE POINT OF
BEGINNING;
CONTAINING:64.19 Acres Gross, more or less.
59.48 Acres Net, more or less.
SUBJECT TO all covenants, rights, rights-of-way and easements of record.
Lawrence L. Bacon, PLS 3527
Lu
a:
x
ul
LLJZ UJ
<
>
w
in M
EXHIBIT B
TEM[ECULA REGIONAL MALL
CITY OF TEMECULA FURNISHED STRUCTURE
Exhibit B-1 Street Improvements
FinW: De=mber 12. 19% 1108 pt 1480121.3 -40-
struct Overland Drive Overcrossing
per CFD 88-12 Improvement Plans
Construct Acceleration/Deceleration Lane
with Driveway Approaches. Install Street
Lights and Sidewalk (East Side)
YNEZ ROAD
00
rO =r
>
C')
F-L 5?
(j)
CD
0 e%
03
CD CD
0
iF
CD4
3 EL 0
(j)
CD c-
f
0 CD
CD
CD
n
fn
('D =r m
E:
M CD m
c:
>
m
0 U) 2
< * 0
CD z
a >
0 r-
CD K
>
(J) CD
Exhibit B-2 Trafric Signals
Final: December 12, 1996 1108 pt 1480121.3 -41-
CL
cn
cn
Cl)
cn
- r
0
0
z 0
r-L
0 cn cn
to
-n
0
CL
m
K
m
r.L 0
c:
>
m
0(n0
0
cn z
>
to0
>
CD
Exhibit B-3 Underground Power Lines
FirW: D@mber 12. 19% 1108 pt 1480121.3 -42-
Oc-t-09-96 04:23P Genoa Real Est-ate Ser-vice 310 544 7477 P.06
W-6@774- ;BF 1. :4S-coc. 95Z! P@ r)C T 37 ee:
CL
CL
rn
r.
m
0 ?L 0
CL c
ml
(A G)
M 00 C)
2 Z
cn CD
OCT-09-1996 16:26 310 544 7477 95% P. 06
Exhibit B-4 Storm Drain Improvements
FiiW: D@mber 12, 19% 110 pt 1480121.3 -43-
oc-t-09-96 04:23P Genoa Real Estate Service 310 S44 7477 P-07
90967672. ;BF pS_coC. 9=-3 P'E,2 OCT 07 S6 W: 16
NMI
YRIZ RW
%
%
%
LO
%
%
%
%
%%
in
c
m
m
CD
OCT-09-1996 16:26 310 544 7477 96% P. O?